【导语】木工承包合同怎么写才规范?本文根据受用户欢迎程度整理了15篇优质的木工承包合同范文,都是标准的书写参考模板,便于您一一对比,找到符合自己需求的范本。以下是15篇木工承包合同范文,希望您能喜欢。
发包方(甲方):
承包方(乙方):
为了明确双方权利和义务,协调工作,确保工程质量和施工进度,使工程顺利如期完成。
依照《中华人民共和国民法典》和国家有关法律、法规的规定,经甲、乙双方协商签定本合同,以资共同遵守。
第一条工程名称:第二条工程地址:第三条施工工期:以上工程自年月日起开工,至年月日止,总日历天数天,完成全部施工任务。
若遇不可抗拒的自然灾害;设计变更;施工渠道受阻,工期延顺。
第四条承包方式及施工内容第五条合同价款该工程共计造价元(大写金额)。
第六条付款办法第七条工程质量及验收乙方应严格按设计要求和国家颁发安装工程技术规程及验收规范进行施工。
如因乙方责任造成返工者,则由乙方承担一切损失。
如因甲方原因造成返工者,则由甲方承担损失。
第八条施工安全施工中由于乙方违犯规程、违章作业所造成的事故或损失,由乙方负责。
第九条违约责任合同一方不履行合同义务,责任方承担违约责任。
第十条合同生效及终止本合同自双方签章之日起生效。
本合同在双方完成约定内容后,即告终止。
第十一条解决纠纷方式本合同未尽事宜或遇有争议、双方协商解决,仍不能达成一致意见者,可向人民法院提出诉讼。
第十二条合同份数本合同一式四份,甲、乙双方各执二份。
甲方(公章):_________法定代表人(签字):__________________年____月____日
甲方:_________________简称甲方
乙方:_________________简称乙方
经协商甲方将贵州广播电视大学金阳新校区一期四标段教学实验楼a、b栋工程木工制作、安装、上下车、机械等委托乙方施工。内容如下:
一、工程内容
a、b栋现有施工图纸、招标文件、图纸会审纪要及设计修改所有含有的木工工程,包括制作安装、预留、钉子、铁丝等工序。
二、单价及承包方式
以建筑面积每平方米15.00元整包干,工程量以施工图为计算依据,人工费、班组管理费、施工工具、机械、铁丝、铁钉、上下车、劳保用品以及现场转运等乙方自行承担。
三、付款方式
完成工程量,主体结构施工完毕且验收合格后,付到总金额的60%,余款,在施工过程中,模板浪费超过3按市场价扣除乙方工程款。
四、质量要求
达到国家现行质量验收标准以及设计要求,经有关部门验收合格为准,如验收不合格所引起的返工所发生的一切费用由乙方自行负责,所耗废的材料按当前市场价从工程款中扣除。模板按缝处漏水泥,拆模后要清理,否则用砂轮机打磨。
五、施工工期
按现场进度计划施工,乙方不得拖延工程进度,中有拖延工期现象,所造成的一切费用由乙方负责。
六、管理
乙方在整个施工过程中,必须服从甲现场管理人员的管理,遵守施工现场管理条例和制度。
七、施工安全要求
1、乙方在施工过程中必须严格执行安全操作规程及有关规定,做到安全生产,文明施工,按照文明施工管理条例实行。
2、杜绝一切违章作业,施工前先检查作业面有无安全隐患,做到及时发现及时处理,乙方必须组织工人进行安全教育以及班前安全活动,施工过程中造成的一切安全事故均由乙方自己承担,并对甲方赔偿相应的损失费。
八、未尽事宜,甲乙双方自行协商解决。
九、本合同一式叁份,办理相关手续一份,甲乙双方各一份,双方签字生效,如有违约合同总10%支付违约金。工程尾款付清后本合同作废。
甲方(公章):_________________乙方(公章):_________________
法定代表人(签字):_________________法定代表人(签字):_________________
_____________年__________月__________日_____________年__________月__________日
木工工程承包合同书如上所述
定作人与承包人之间定立承包合同,一般是建立在对承包人的能力、条件行人的基础上。只有承包人自己完成工作才符合定作人的要求。今天小编要与大家分享的是:包木工承包合同相关范本。具体内容如下,欢迎参考阅读!
包木工承包合同范本一
发包单位: 简称甲方
承包单位: 简称乙方
根据甲乙双方协商同意将 模板分部 工程发包给乙方,按本工程实际情况签订施工协议书,具体条文如下:
一、所属工程承包施工内容
1、对木工在施工中的要求:
首先要认真熟悉施工图纸,对项目部所发的变更资料,技术交底,安全交底认真执行;
施工过程中对完成的工程量每天要及时对照规范自检,及时整改,杜绝返工;
有节约材料的指导思想,认真进行模板工程劳务承包协议书的配制及开具租赁材料料单;每个工作面施工完毕剩余材料应及时清理到原堆放地点;
要有文明施工的指导思想,做到材料堆放整齐,拆除后材料不得从楼面往下扔;
每天做到施工用具清理入库,摆放整齐,整个木工区域内有人清扫;
施工中模板拆除后应清理、整修、上脱模剂、分类堆放到指定地点,保持场面道路畅通;
在整个施工过程中,木工班长始终在现场,进行协调工作,始终有负责技术的管理人员在现场配合项目部进行质量及安全检查和监督管理,乙方木工班长是 、技术管理员是 ;
在整个施工过程中,所有材料需用井字架、塔吊进行垂直运输的应听从项目部的安排,不得自行操作;
配合其他工程的工作,如配合水电工的墙、地面的留洞、留槽等;
爱护甲方提供的安全防护设施,对有安全隐患的部位应停止作业,及时通知项目部采取措施消除隐患;
2、甲方仅提供乙方以下工具:a)翻斗车 b)板车 c)塔吊 d)井架 e)高凳 f)跳板。
由乙方自带和采购的小型机具、安全帽(带)及劳保用品。如安全帽(带)、雨衣、胶鞋、手套、灰桶、洋锹、洋镐、墙线、凿子、郎头、扫帚等所有除甲方提供施工机具外用木工必须自带所有施工机械,包括混凝土表面的打磨机械和凿混凝土的工具及用品。
二、工期要求:
1、开工日期按甲方签证的开工日期 年 月 日为准。
2、总工期为 天,竣工日期 年 月 日。
具体施工进度根据甲方所安排的进度计划严格执行如期完成。从浇砼垫层开工期:c: 日历天;b: 日历天;a: 日历天。
三、总的施工要求:
依照本工程施工图,施工说明书及变更、按国家建委颁发的建筑安装工程验收规范及有关补充规定执行,具体验收规范及有关补充规定执行。
四、进度质量奖罚:
1、甲方现场安排总进度计划,进度不能如期完成,每延期一天罚款 100 元,周进度计划,每延期一天罚款 100 元。
2、本工程主体模板分项必须确保优质主体结构,如模板分部达不到优质主体,主体扣除 2 元/m2,主体验收作一次评价。
3、在施工过程中发现质量问题必须及时返工重做,以返工材料价格五倍赔偿。
4、工程中所有的质量、安全、文明施工等问题,现场施工员有权做出处罚,罚款在生活费或工资款中扣除。
五、安全达标要求:
本工程在施工过程中必须严格按照国家颁布的建筑安全技术操作规程施工。
六、工程中所用的建筑材料全部由甲方供应到工地现场,如发生材料不能及时供应,脱节由甲、乙双方共同协商办理停工签证手续。
七、各工程承包价格如下
(1) c厂房 元/㎡、b厂房 元/㎡ 主体结构达到优质;不粉刷按c厂房 元/㎡、b厂房 元/㎡ 结算 。a厂房暂定由乙方施工,如b、c厂房施工质量达不到优质主体,甲方有权另行发包给其它班组。a厂模板承包价为 元/㎡,质量及其它各方面做得较好将另行奖励0.5~1元/㎡;做不好时扣0.5~1元/㎡。
(2)以上分部工程,甲方根据实际情况有权另行安排其他队伍施工,施工的每分部单价按以上单价在总价内扣除。
(3)在每一分部工程施工前甲、乙双方必须另签施工协议,如分部不签施工协议,该分部不得清帐。
2、生活费发放按甲方所排工程进度发放,具体每月生活费发放金额按每月各工种实际出勤施工人数,按 15 元/天计算,生活费发放必须经过现场管理人员签字后报项目经理部审批。人工工资在春节之前付已完成工作量的70%以上,余款一年内结清。
3、工程竣工后,余款待一年内逐步付清。
九、社会综合治理:
1、所有参加施工人员必须具有身体证并办理所需办理的一切证件,服从一切管理规定。
2、住宿文明、集体宿舍内严禁男女混合居住,发现一次罚款1000元,严禁违章计划生育人员在宿舍住宿或做工。
3、甲方提供施工人员集体宿舍居住,任何施工人员一律不准搬进新盖楼房居住,发现一次罚款500元。
4、接电源,烧电饭煲、电炒锅、电炉等,发现一次罚款500元。
5、生活区内食堂不得自行烧饭烧菜,饭盒统一编号,食堂应清洁无蚊蝇。按甲方卫生要求统一蒸饭、烧菜分工种自行负责,服从项目部统一指挥,乙方安排卫生员负责生活区、食堂、厕所等卫生工作。
6、本工程总包价包括就业费、暂住证费及卫生防疫证费用。
十、现场文明管理:
1、所有施工人员进入施工管理必须戴好安全帽、系好安全带、严禁穿拖鞋赤膊。
2、现场保持整洁,所有建筑垃圾及时处理干净,做到工完料净,临时施工道路每日清扫。
3、施工机械完工后应清洗干净、上油,所有工具归纳到指定位置,小车摆放整齐,配电箱专人上锁保管钥匙,井字架由专人开完工后拉切断电源,以上每发现一次不按要求,罚款100元/次。
4、各班组使用电动机械如雨淋和人为造成损坏要该班组承担责任,修理费用赔偿。
5、在本地上每发生一次打架行为罚款每人500元,情况严重甲方有权移交公安机关处理并令其离开本工地。
6、各工种负责把自己工种材料堆放整齐、清理干净。
7、工地现场文明施工及材料的浪费,按现场施工负责人要求进行罚款。浪费材料按材料费的五倍罚款。
十一、其它:
1、途中违约按完成工作量的60%付款,三天之内人员全部撤离工地。甲方重新安排施工队伍进场,费用由乙方承担,如果独完成主体后违约,其主体工程按总造价的60%计算。
2、本协议甲乙双方慎照执行,一式四份,承包方执一份,双方签字后生效。
3、其它未尽事宜,双方协商解决。
甲方签字(盖章): 乙方签字(盖章):
年 月 日 年 月 日
包木工承包合同范本二
甲方: (简称:甲方)
乙方: (简称:乙方)
经甲乙双方共同协商,甲方将 项目
工程以包工,包制模,铁钉,铁线,电缆,电锯电片及机械所有的电缆电线工具,包图纸上木工制安及所有木工工程一次性承包给乙方施工,为安全保质保量金,工程结束后给予返还。
一,承包单价;乙方所承包的木工工程,其单价按建筑面积的( )元/㎡(包括基础地下室设施及屋顶斜屋面n型线条主体),按此单价为最终结算价,甲方不另追加乙方任何费用,面积计算以图纸为准。
二,承包范围;乙方按设计图纸,设计变更完成该工程所有的木工工程,(含附属零星工程木工及基础设施的制安,负责工程完工后,所有的模板,方条,顶木,步步紧,方条等的清理及按甲方要求制定的地方分类堆放好)。
三,乙方负责:
1.乙方应付责组织本工程所需要的熟练工人,机械工具辅助材料,熟悉施工图纸规格按照设计图纸施工规范及安全生产条列,进度计划国家品质标准施工。
2.服从项目管理人员及施工员统一指挥,调配和检查,遵守项目人员制定的各项规章制度,不准随意浪费甲方原材料,如发现乙方随意浪费,甲方有权要求乙方按原价加倍赔偿。
3.乙方不得在工地上无理取闹不服从甲方现场管理人员统一指挥调度及阻止别的施工班组施工的,发现一次罚款500元,累次不改甲方有权单方面终止合同,乙方按实际完成工程量的60%结算,并自动退场。
4.主体施工过程中,乙方应按时,按质,按量完成施工任务。不准有爆木。漏浆现象,发现有出以每处50200元罚款,并即时处理,因木工验收不合格造成返工,甲方有权要求乙方加倍赔偿一切浪费的原材料及需别的施工班组配合返工所需人工工资,工程所有爆木,漏浆处,乙方应及时处理掉。尾期工程中需要制安的应随叫随到,不到的话,甲方有权请他人做,其工资按市场价格双倍从乙方未付工程款中扣除,影响工期的按合同规定处罚,乙方应无异议。
四,甲方负责;
1.负责对乙方的图纸技术交底及安全三级教育,指导,检查乙方施工过程中的施工质量。
2.按合同约定按时支付工程款。
3.无偿提供乙方的住宿及生活用水用电,(不含电磁炉用电)
五,工期要求;
1.乙方应严格按照项目部制定的各项施工进度计划进行施工,具体进度计划按项目部制定的施工进度计划。
2.乙方不能按甲方进度计划完成工期内的工程量时,甲方有权高价在外面请人帮忙完成,乙方无权阻扰,其工资从乙方工程进度款中扣取,工期拖延一天处以5005000元的工期处罚金,按工期计划乙方提前完成应给与奖励。
3.因乙方原因造成工程停工三天以上,甲方有权单方面终止合同另找施工队,结算按实际完成工程量的60%结算,结算时间按工程主体全部封顶后结算,余下的部分作为重组新班组和甲方的损失费用。
六;质量标准;
规格按照施工图纸设计变更通知及现行的国家有关强制性规范规定施工,并达到国家工程品质验收合格标准,如有返工给甲方造成材料浪费或延误工期的,甲方有权追究其赔偿责任并罚款,费用从乙方工资中扣回。
七,安全要求;
1.乙方工人进入施工现场都必须遵守安全操作规程,佩戴安全帽,穿工作服,穿胶鞋上班。
2.上班时间不许喝酒,打闹,严格安全生产条例方针,及项目部组织所要求的安全知识讲座内容交底,进行施工。
3.如乙方在施工过程所造成的任何安全事故,由乙方负全部责任和费用及事后处理,与甲方无关。
4.不带安全帽,穿拖鞋,喝酒上班的发现一次每人每次30元罚款,此款从工资中扣除,并通报批评,现场严禁带小孩或社会闲杂人员进入工地,住宿,逗留。
八,付款方式;本工程第一次按工程总量的三楼付款80%,然后按月进度工程量的80%付款。余款在完成承包内工作后两个月内结清。
九,本合同未尽事宜,双方可根据情况随时协商补充,补充协议与本合同具有同等效力。
十,本合同书自签字之日起生效,工程竣工,工程款全部结清后本民法典律效力自行终止。
十一,本协议一式两份,双方各持一份,同时具有相应法律效力。
甲方(签章) 乙方(签章)
二o一o年 月 日 二o一o年 月 日
发包人:(以下简称甲方)
承包人:(以下简称乙方)
依照《民法典》、《中华人民共和国建筑法》及有关法规,遵循平等、自愿、公平和诚实信用的原则,双方就本工程施工事宜协商一致,订立本合同。
一、工程概况:
工程名称:
工程地点:
建筑面积:
工程结构:
二、分部(木工)分包范围:
甲方承接的工程的所有木工施工任务以包工包料的形式由乙方承包,其承包范围包括:(1)材料:木方楞、多层板18厚,对拉螺杆螺帽、伞形卡、铁丝、铁钉、洞口防护的模板和方木(包括木工分部工程中的所有材料);(2)木工工种中所用的全部机械设备;(3)工程中所有钢筋砼结构、砼预制构件的支拆模,安装预埋铁件、预留孔洞等所有人工。
三、工程质量要求:
1、在本工种(分部)施工中必须执行《工程建设标准强制性条文》及《建筑施工规范》施工,达到合格结构标准;若造成质量问题,达不到验收标准,所造成返工的一切经济损失(包括人工、材料、工期)均由乙方承担,并根据性质轻重,并处以100-1000元/次的罚款。注:柱漏浆清理,柱支模前必须冲洗干净,一层必须用新模板支模,所有的砼表面均要平整,梁底按规定起拱,柱角垂直度偏差在2以内,且不能缺角,达到清水砼结构要求。
2、在主体结构支模架、模板施工中,班组先自检、经项目部施工员、质检员检查后,报监理公司及建设工程主管部门复检。
四、安全生产管理制度要求:
1、录用施工人员必须有有效身份证、计生证,年满55周岁以上不得录用,上岗前进行安全三级教育,每个工人都必须安全知识测试,填写安全教育卡,贴上1寸照片。
2、进入施工现场必须戴好安全帽、系好帽扣,高空作业系好安全带,违者处罚50元/次(安全帽及劳保用品由甲方定点统一购买,结算时按发票价格扣除乙方工程款)。
3、特殊工种必须持证上岗,杜绝与本工地无关的人员进入本施工现场及生活区,特别是妇女儿童,更不能留宿工地,违者处以50-100元/人次(本工种凡带妇女儿童的一律到外面租房子,费用自负)。
4、禁止在生活区自行开火做饭,违者没收用具并处以100-200元/次的处罚,生活区职工宿舍每间住足项目部规定的人数。
5、本工种凡属本人、人为及违反安全生产操作规程和没有遵守安全生产管理制度的伤亡事故,一切的经济损失及刑事责任均由乙方负担;在施工现场不得故意损坏项目部财物,发现以一罚十处理;工地内严禁打架斗殴,若发生打架斗殴,当事人处罚200元/次,乙方负责人处罚500元/次。
6、在施工中和生活区不得私自乱拉乱接电线,工程上需用电,必须找现场电工操作接电,自行接电违者处以罚款200元/次,本工种的施工机械必须设有防护装置,不得在现场和生活区生火取暖。
五、文明施工标化工地要求:
1、本工程必须达到的标准;分包单位在选用施工作业人员技术素质的同时,要讲做人道德素质,更不能使用社会上的闲散人员,特别是作案在逃人员进入施工现场,如有违犯,甲方有权同有关部门联系,并移交到执法部门处理。
2、在施工过程中的每道工序必须做到工完场清,项目部通知须做到工完场清的部位在四小时内必须清理完毕,否则项目部派人清理后,扣除乙方每工60元。施工机械要及时做好防护装置及保养工作。本工种范围内的建筑垃圾废料要及时清运出场,如发现没有及时清运出场,甲方有权找临时工清运,其费用由甲方在结算时扣除乙方的产值,乙方无条件执行。
六、工程的价款及结算付款:
1、本工程根据施工图实际按具体的当地预算定额模板费用结算(预算定额模板费用中应扣回汽车式起重机、卷扬机连架等垂直运输费),乙方工程质量、进度经建设主管部门评定,乙方必须做到质量合格。
2、结算付款分阶段实际完成的工作量:基础砼完成、二层楼面砼完、砼结构全部完(具体可以双方另行协商)。每次款到位后按每阶段所完成的产值各付85%,主体结顶验收达到结构合格标准后一个月付至90%,单位工程竣工验收后二个月内付清(具体可以双方另行协商),每阶段付款时先由现场管理人员签后,再由总包负责人签发放工程款,但人工工资乙方必须在当月付至85%,每年春节前及退场人员工资必须全额付清(如不付清有关部门追查的责任由乙方承担)。
七、质量、安全、文明施工保证金要求:因考虑到本工种的周转材料费用,有一定的资金投入,保证金万元,合同签订后七天内汇入项目账户(不计息),保证金待基础浇捣完成,业主款到位后三天内退还。但乙方在施工中质量达不到合格标准,安全、文明施工达不到标化标准的,甲方有权扣乙方产值总额的5%,从保证金中扣除,乙方无条件提出拒绝,必须执行本合同条文的规定。
八、按分阶段付款的同时,但建设单位款额没有到位的情况下,乙方工人的生活费由乙方自行支付,如乙方因没生活费而停工,若停工的一切损失(包括影响各工种施工进度,工期及经济损失)均由乙方负担,乙方决不怨言反对甲方的处理措施。
九、乙方必须按甲方的施工进度计划,确保周转材料,准备足够的劳动力,不得以任何理由如经济困难进不到材料,及农忙、节假日、有人生病等条件延误工期,否则所造成的一切经济损失均由乙方承担(按甲方制定的周、月工期每拖延一天罚1000元,拖延工期十天以上处罚贰万元,并赔偿各工种进度损失)。
十、进入施工现场的施工人员须办理造册登记手续,上交身份证复印件二张,1寸照片5张,便于办理暂住证。务工人员的婚育证由其本人在户口所在地办理好带到本工地交项目部(办证费用由乙方负责)。
十一、项目部安排本工种施工人员在现场住宿70%左右,其余人员由乙方自行解决外面租房,费用自理。
十二、未详事宜双方协商解决,如协商无效,交当地仲裁委裁决,本合同一式三份,甲方贰份,乙方壹份,双方签后生效,工完款清后失效。
甲方:乙方:
代表:代表:
电话:电话:
一旦承包工程是要签订相关的 承包合同 的,既保障了工程的实施进步,也维护了签订双方的合法权益。今天小编就给大家整理了承包合同,有需要的来阅读哦 木工班组承包合同参考 甲方: 劳务公司 (以下简称甲方) 乙方: 班组 (以下简称乙方) 根据甲方承建工程任务的需要,经甲、乙双方友好协商,在平等互利,友好合作的基础上,甲方将模板制作、安装、拆除以内部劳务清包的形式承包给乙方施工。为明确甲、乙双方职责、权利,特签定本协议,以资双方共同遵守执行。具体条款如下:
一、 工程名称: 模板安装、拆除
二、 工程地址:
三、 结构类型:
四、 建筑面积:
五、 承包方式:包清工、包限额领料、包质量、包安全、包进度(包工期)包文明施工。
六、 承包内容及要求: 模板工程:
1、场内地面、楼层的模板、支撑架料、扣件的水平运输、垂直运输以及结构楼层中(内、外)的模板安装时的水平标高(配合除轴线外的施工放线)多层顶板支撑板带。
2、根据设计图纸或模板翻样图加工模板,安装前墙、柱、梁、现浇板模板内垃圾的清理,浇砼时护模。按施工图纸及验收规范进行模板安装,安装完毕模板内垃圾的清理,墙根、柱脚因支模原因造成砼膨胀的剔打垃圾的清运。主体结构的剔打,修补等。模板每两层刷一次隔离剂。
3、拆除模板的清理、校正,材料分规格、型号运输到指定位置的堆码并拔除层板、木方上的钉子。砼导墙模板的支、拆、零星构件模板(含所有小模板、构造柱模板等)的安装、拆除,按图纸设计交底予留孔洞的留设,及安装所使用的洞口的封堵(含下水道洞口、烟道洞口等)予埋铁件的安放等工作(含所有预制构件模板、予留盒的制作、安装对拉螺杆的制作等楼梯踏步的保护模板制作、安放等)
4、所有模板工程必须达到市优质结构要求。模板的最大接缝宽度控制在10以内,模板的周转使用时要将表面清洁干净,以保证砼的外观质量。
5、工作范围内的文明标化、清理卫生等。
6、设计院和建设单位对本工程的变更而发生的增减工程量。
7、承包工程范围内的安全、文明施工等。生产性临时的搭设、拆除等。
七、分项承包单价: 序号 分项名称 单位 单 价 (元实际面积) 备注 优良 安全 进度 文明施工 零星材料(铁钉等) 1 模板制作、安装 ㎡ 砼接触面积 2 模板拆除 ㎡ 砼接触面积 说明:
1、 凡承包施工范围内不再另发生任何计时工。达不到甲方要求质量标准按80%结算。
2、 此单价包括税金(结算时扣除税金4.16%)其中营业税综合3.56%, 个人所得税 0.6%.
3、 此单价已包括质量、安全、进度、文明施工、工具费用等若出现安全事故降低3元㎡若出现工期进度达不到项目部要求,当期工程量降低3元㎡若出现文明施工达不到项目部要求降低3元㎡.
4、 木工工具包括在施工中所使用的一切工具均由乙方负责(电钻、电锤、手提刨木机、零星工具等)
5、 零星材料由甲方提供(甲方按定额测定含量,乙方按规定使用,若超过部分由承包班组自行负责)
八、工质量标准:100%优良率,____省优质结构工程。根据质量要求标准,承包班组必须严格按照隐蔽工程质量验收标准和施工规范,作好每道工序施工,每道工序完工后班组必须先做好自检,互检工作然后通知甲方,总包单位及监理单位验收。经验收达到质量标准方可进行下道工序,达不到质量标准必须认真按照验收提出的整改措施和要求进行整改,直到达到标准为止。如经整改仍然达不到要求乙方必须承担双倍的发生总包方对甲方的罚款处罚,作为对甲方信誉的赔偿。
九、工期要求: 总工期 天(按甲方单位的进度计划执行)若在要求工期内不能完工,造成总包方对甲方的工期罚款,根据乙方承包总价按相应的比例给予双倍处罚。作业班组承包方必须确保工期,每延误____日历天罚款人民币壹万元整。
十、安全要求及综合治理
1、各承包组必须认真学习和掌握安全生产管理条例和操作规程,严格按照安全操作规程施工。如违反安全操作规程违章作业造成的安全事故,由违章者自负全部责任。
2、严格遵守和国家及____省的各种法律 法规 ,服从总包及甲方等相关部门的指挥,自觉遵守和执行总包及甲方的规章制度。如在施工过程中发生安全事故产生的费用在3000.00元以内由班组自付,3000.00元1万以内的甲方负责一半,一万以上甲方负责总费用的60%。2万以上的安全事故由安全部门协助处理。
3、承包班组进入施工现场各相关证件必须齐全并交复印件及花名册一份交甲方备案。
4、进入施工现场必须正确使用和佩带各种安全防护用品,必须xx全帽和系好安全带,如发现不xx全帽和不系安全带给予10元人次罚款,违反安全操作规程的和未经主管部门同意任意拆除安全防护的视情节严重处以50100元罚款。
5、宿舍内严禁乱拉乱接电线,严禁在宿舍内烧煮食物,一经发现除没收炊具外并处以200元以上一次罚款。
6、严禁 打架斗殴 、 嫖娼 、赌博,如有发现先给予双方处以xxx元罚款,然后根据调查结果,责任方承担另一方的全部损失,情节严重者移交司法部门处理。
7、严禁在宿舍内男女混居、工地上严禁带家属,若出现带家属给予500.00元人一次的罚款,若出现混居现象给予1000.00元人一次的罚款未经主管部门同意不得留宿非本班组人员,每发现一次给予200元人次处罚,爱护公物,不得损坏各种设施。
8、凡在施工区域外发生的治安事件,均由乙方自行负责。 十
一、甲方职责:
1、负责对乙方进行质量、安全、进度、文明施工,操作规范等技术交底。
2、对乙方进场后的施工能力、人员素质、技术素质、进行考核,给予乙方30天的 试用期 ,如试用期内乙方达不到质量、进度、文明施工、综合治理要求的甲方有权单方终止协议,其施工部分工程量不予结算,作为对甲方信誉损失的赔偿。造成对甲方经济损失的乙方给予赔偿。
3、根据现场条件,提供乙方的食、宿、其费用乙方自理(电每月30度、超出度数按照1.00元度扣除)
4、积极为乙方创造施工条件,做好协调工作。
5、负责对乙方的质量、安全、进度、文明施工进行监督检查,对不符合要求的提出整改意见和措施。如乙方整改达不到要求或不予整改,甲方有权派人进行整改,其费用按整改部分工作量费用的两倍从乙方人工费中扣除。 十
二、乙方职责:
1、根据承包工程量组织相应的施工人员,进场人员必须合理搭配,其思想素质好,技术能力强,无健康疾病和传染病的1845岁男性。各承包班组有一名组织能力强、技术好,责任心强的同志作班组长,形成系统管理。同时该班组长未经甲方现场主管人员批准不得离开现场,积极参加甲方或总包方组织的相关会议,凡擅自离开现场或不参加应该参加的会议给予50100元次罚款。
2、熟悉施工图纸,严格按照《建筑安装工程施工与验收规范》及设计要求,进行组织施工,确保工程质量、进度、安全、因管理不善达不到质量标准造成的返工,应负担由此造成的工料、工期损失。
3、乙方进场人必须相对稳定,未经甲方同意不得随意变动班组人员。
4、接受甲方对质量、安全、文明施工等进行的技术交底、教育和监督,服从指挥。
5、对甲方提出的整改意见应即时组织人员进行整改,直至达到标准为止。
6、爱护甲方提供的各种设施和设备,不得随意损坏,如有损坏则给予其价值的两倍予以赔偿和处罚。 十
三、文明标化、卫生要求:
1、认真搞好个人、宿舍、现场卫生,随时保持文明清洁。
2、认真按照文明标化样板工地要求及优质结构标准,对自己承包范围内的材料分类、分规格、分型号堆放整齐。
3、每道工序完工,必须做好工完场清工作,能用的材料必须利用。
4、凡以上达不到要求者,根据其性质、范围及价值给予两倍以上的罚款,每次每项最低不少于20元。
5、本工程为无等级事故工地,确保________市级标化,安全文明工地,达不到市级标化,安全文明工地对乙方罚款5.00元建筑面积。
6、因作业班组原因发生的安全事故,由作业班组自己负责,给甲方造成的损失由作业班组承担赔偿。
7、作业班组必须有详细的安全教育、检查记录。
8、进入施工现场人员统一工作制服,统一上岗胸牌,费用由作业班组承担。 十
四、材料管理:
1、乙方应按照标准化文明施工的要求,对自己承包区域内的材料分类、分规格型号堆码整齐。每道工序完成必须做到工完场清,能使用的材料必须使用。
2、完工后对周转材料的修理、清理,拨除层板上和木枋上的铁钉,按指定地点堆码整齐,移交给甲方现场材料员清点验收。甲方现场材料员填写验收单据,双方签字,作为办理工程结算的凭据。如乙方不办理此手续,甲方将按照模板面积0.50元 ㎡从结算中扣除。
3、乙方领用应由甲方供应材料应严格执行领退料制度,(各种周转材料按定额计算损耗,扣件损耗率1%山型卡损耗率3%)如乙方归还不够领料数量,将按市场价全额赔偿。(包括乙方支撑不牢胀模造成的材料浪费、人工损失) 十
五、设施、工具供应: 除大型机械设备甲方供应外,小型设备、工具乙方自备(包括班组工人的安全帽等等) 十
六、人工费结算及支付:
1、为保证工程质量、进度、各施工班组签定合同时,向甲方缴纳300xxxx5000元 保证金 。该费用工程结束后、质量进度均达到甲方要求者,一次性退还乙方。
2、乙方进场后自垫生活费至工程0.000以后甲方每月支付乙方生活费650元人(按登记出勤人数)
3、结算方式:按实际面积计算。结构阶段结束(小模板全部拆除)后,按分项承包结算总价80%支付乙方(含借支生活费及罚款)结构工程竣工验收后(大小模板全部拆除并清运完)根据相应的质量等级单价和总价支付总价的10%,(质量标准以质检站核定为准),留10%作为工程押金。待装修完支付给乙方。
4、在施工期间,如属于甲方原因造成停工在7天以上,工地上又确无办法安排其它工作的情况下,甲方向乙方支付每人每天10元基本生活费。 十
七、其他:
1、班组进退场(包括任何形式的中途退场),甲方按乙方所做合格工程量进行结算外,不再承担其他任何费用。
2、本协议如有未尽事宜,经甲、乙双方协商,另签补充协议。
3、本协议一式三份,甲方执两份,乙方执一份。
4、本协议自签字之日起生效至 工程款 全部付清自动失效。 甲方: 乙方: 负责人: 经办人:________年____月____日 建筑工程木工承包合同 装修人: (以下简称甲方) 装饰装修企业: (以下简称乙方) 根据《 民法典 》、中华人民共和国建设部令《住宅室内装饰装修管理办法》及有关规定,经甲乙双方协商一致,签订本合同。
一、装饰施工项目
1、装饰工程地点:
2、房屋结构:
3、装饰施工内容及要求:详见附表
1-
1、
1-2:家庭居室装饰装修工程施工项目确认表
(一)
(二)附表2:家庭居室装饰装修工程设计图纸,一式二份,甲乙双方各一份,并双方各一份,并双方确认.
4、 工程承包方式:双方商定采取下列第 种承包方式:
(1)乙方包工、包料(详见附表第5:装修企业提供装饰装修材料明细表)
(2)乙方包、部分包料,甲方提供部分材料(详见附表4:装修人提供装饰装修材料明细表)
(3)乙方包工、甲方包料,即清包工(详见附表4:装修人提供装饰装修材料明细表)
二、工程期限 工程期限 天,开工日期:________年____月____日,竣工日期:________年____月____日。 出现以下情形经发包方人确认,工程相应顺延:
(1)工程量变化和设计变更
(2)不可抗力
(3)发包人同意顺延的其他情况。 如因项目变更经双方协商,工程相应调整。
三、工程造价及付款方式
1、工程总造价:(大写)(小写)元, 其中含:设计费元,管理费元,税金元(详见附表3:家庭居室装饰装修工程报价单)
2、付款方式:合同约定的开工日期前____日,甲方支付工程总价款的40%,计元,其余价款根据施工进度计划分期支付
(1)木工进场前,支付总价款40%,计元
(2)油漆工进场前,支付总价款17%,计元
(3)余款3%元,工程验收合格后一次付清。 包清工工程,开工前工程款一次付清。 凡因工程量变化、设计方案等原因调整工程造价的,应在工程验收合格后按工程决算结清。 双方款项往来,均就出具发票或正式收据。
四、材料、设备的供应
1、甲方提供的材料、设备见附表4: 本工程甲方负责采购供应的材料、设备,应符合国家规定的质量标准、环保标准,否则由此引发发产品质量问题和其他问题、乙方不承担责任。甲方负责供应的材料应按施工进度计划及供应到现场,经乙方验收签字,并由乙方负责保管。由于保管不当造成损失的,由乙方负责赔偿。
2、乙方采购的材料、设备见附表5: 凡由乙方采购的材料、设备必须与报价单中注明的品牌、规格、型号、质量相符,并应向业主提交检测报告,其中包括环保检测资料。 乙方采购的材料、设备,应符合国家标准,否则对工程造成的损失由乙方负责如乙方采购的材料、设备是经甲方指定的,出现质量问题,乙方不承担责任。 木工 工程承包合同 范本 发包单位:简称甲方 承包单位:简称乙方 根据甲乙双方协商同意将模板分部工程发包给乙方,按本工程实际情况签订施工协议书,具体条文如下:
一、所属工程承包施工内容
1、对木工在施工中的要求: 首先要认真熟悉施工图纸,对项目部所发的变更资料,技术交底,安全交底认真执行 施工过程中对完成的工程量每天要及时对照规范自检,及时整改,杜绝返工 有节约材料的指导思想,认真进行模板工程劳务承包协议书的配制及开具租赁材料料单每个工作面施工完毕剩余材料应及时清理到原堆放地点 要有文明施工的指导思想,做到材料堆放整齐,拆除后材料不得从楼面往下扔 每天做到施工用具清理入库,摆放整齐,整个木工区域内有人清扫 施工中模板拆除后应清理、整修、上脱模剂、分类堆放到指定地点,保持场面道路畅通 在整个施工过程中,木工班长始终在现场,进行协调工作,始终有负责技术的管理人员在现场配合项目部进行质量及安全检查和监督管理,乙方木工班长是、技术管理员是 在整个施工过程中,所有材料需用井字架、塔吊进行垂直运输的应听从项目部的安排,不得自行操作 配合其他工程的工作,如配合水电工的墙、地面的留洞、留槽等 爱护甲方提供的安全防护设施,对有安全隐患的部位应停止作业,及时通知项目部采取措施消除隐患
2、甲方仅提供乙方以下工具:
a)翻斗车
b)板车
c)塔吊
d)井架
e)高凳
f)跳板。 由乙方自带和采购的小型机具、安全帽(带)及劳保用品。如安全帽(带)、雨衣、胶鞋、手套、灰桶、洋锹、洋镐、墙线、凿子、郎头、扫帚等所有除甲方提供施工机具外用木工必须自带所有施工机械,包括混凝土表面的打磨机械和凿混凝土的工具及用品。
二、工期要求:
1、开工日期按甲方签证的开工日期________年____月____日为准。
2、总工期为天,竣工日期________年____月____日。 具体施工进度根据甲方所安排的进度计划严格执行如期完成。从浇砼垫层开工期:c:日历天b:日历天a:日历天。
三、总的施工要求: 依照本工程施工图,施工说明书及变更、按国家建委颁发的建筑安装工程验收规范及有关补充规定执行,具体验收规范及有关补充规定执行。
四、进度质量奖罚:
1、甲方现场安排总进度计划,进度不能如期完成,每延期一天罚款100元,周进度计划,每延期一天罚款100元。
2、本工程主体模板分项必须确保优质主体结构,如模板分部达不到优质主体,主体扣除2元2,主体验收作一次评价。
3、在施工过程中发现质量问题必须及时返工重做,以返工材料价格五倍赔偿。
4、工程中所有的质量、安全、文明施工等问题,现场施工员有权做出处罚,罚款在生活费或 工资 款中扣除。
五、安全达标要求: 本工程在施工过程中必须严格按照国家颁布的建筑安全技术操作规程施工。
六、工程中所用的建筑材料全部由甲方供应到工地现场,如发生材料不能及时供应,脱节由甲、乙双方共同协商办理停工签证手续。
七、各工程承包价格如下
(1)c厂房元㎡、b厂房元㎡主体结构达到优质不粉刷按c厂房元㎡、b厂房元㎡结算。a厂房暂定由乙方施工,如b、c厂房施工质量达不到优质主体,甲方有权另行发包给其它班组。a厂模板承包价为元㎡,质量及其它各方面做得较好将另行奖励0.51元㎡做不好时扣0.51元㎡
(2)以上分部工程,甲方根据实际情况有权另行安排其他队伍施工,施工的每分部单价按以上单价在总价内扣除。
(3)在每一分部工程施工前甲、乙双方必须另签施工协议,如分部不签施工协议,该分部不得清帐。
2、生活费发放按甲方所排工程进度发放,具体每月生活费发放金额按每月各工种实际出勤施工人数,按15元天计算,生活费发放必须经过现场管理人员签字后报项目经理部审批。人工工资在春节之前付已完成工作量的70%以上,余款________年内结清。
3、工程竣工后,余款待________年内逐步付清。
九、社会综合治理:
1、所有参加施工人员必须具有身体证并办理所需办理的一切证件,服从一切管理规定。
2、住宿文明、集体宿舍内严禁男女混合居住,发现一次罚款1000元,严禁违章计划生育人员在宿舍住宿或做工。
3、甲方提供施工人员集体宿舍居住,任何施工人员一律不准搬进新盖楼房居住,发现一次罚款500元。
4、接电源,烧电饭煲、电炒锅、电炉等,发现一次罚款500元。
5、生活区内食堂不得自行烧饭烧菜,饭盒统一编号,食堂应清洁无蚊蝇。按甲方卫生要求统一蒸饭、烧菜分工种自行负责,服从项目部统一指挥,乙方安排卫生员负责生活区、食堂、厕所等卫生工作。
6、本工程总包价包括就业费、暂住证费及卫生防疫证费用。
十、现场文明管理:
1、所有施工人员进入施工管理必须戴好安全帽、系好安全带、严禁穿拖鞋赤膊。
2、现场保持整洁,所有建筑垃圾及时处理干净,做到工完料净,临时施工道路每日清扫。
3、施工机械完工后应清洗干净、上油,所有工具归纳到指定位置,小车摆放整齐,配电箱专人上锁保管钥匙,井字架由专人开完工后拉切断电源,以上每发现一次不按要求,罚款100元次。
4、各班组使用电动机械如雨淋和人为造成损坏要该班组承担责任,修理费用赔偿。
5、在本地上每发生一次打架行为罚款每人500元,情况严重甲方有权移交公安机关处理并令其离开本工地。
6、各工种负责把自己工种材料堆放整齐、清理干净。
7、工地现场文明施工及材料的浪费,按现场施工负责人要求进行罚款。浪费材料按材料费的五倍罚款。 十
一、其它:
1、途中违约按完成工作量的60%付款,三天之内人员全部撤离工地。甲方重新安排施工队伍进场,费用由乙方承担,如果独完成主体后违约,其主体工程按总造价的60%计算。
2、本协议甲乙双方慎照执行,一式四份,承包方执一份,双方签字后生效。
3、其它未尽事宜,双方协商解决。 甲方签字(盖章):乙方签字(盖章):________年____月____日________年____月____日
发包方(以下简称甲方):
承包方(以下简称乙方):
依照《中华人民共和国民法典》、《中华人民共和国建筑法》及其它有关法律、行政法规、遵循平等、自愿、公平和诚信的原则,双方就建设工程施工事项协商一致,特订立合同如下:
一、工程概况
1、工程结构:砖混;
2、建筑面积:约㎡(按实际建筑面积计算为准)。
二、承包方式土建工程总单包(即包工不包料)。
三、甲方负责范围甲方应提供水、电、路三通及所有建筑材料、回填。
四、乙方承包范围
1、基地平整、砼工程、砖砌体工程、木工搭拆(铁丝钉子自备)、钢筋工程、内外粉刷工程、楼梯粉刷上顶(一层、顶层、地坪)。
2、乙方自备机械、脚手架。
五、承包价格按每平方米元结算,隔热层按计算。
六、质量要求七、付款方式
1、基础完工付款
2、每层砌体完工付款
3、内粉完工付款
4、外粉完工付款
5、竣工验收合同后付清余款。
八、施工日期:按120天计算,雨天顺延。
九、安全问题乙方应安全、文明施工,如出现大小事故由乙方自负。
十、未尽事宜,甲乙双方协商解决。
十一、本合同一式两份,甲、乙双方签字之日起生效。
甲方(公章):_________乙方(公章):_________
法定代表人(签字):_________法定代表人(签字):____________
木工,是一门工艺,一门独有的技术,也是建筑常用的技术,家装木工承包合同怎么写呢 以下是小编整理的家装木工承包合同,欢迎参考阅读。
家装木工承包合同范文一
甲方:(发包方)
乙方:(承包方)
本着互相信任的原则,就甲方的木工工程达成以下协议。
第一条 工程概况
1、装修施工地点:
2、工期:
3、本项工程预计费用元人民币。
第二条 材料供应的约定
1、甲方提供的材料
乙方必须至少提前三天向甲方提出下一工序需要购买的材料清单,并注明所需要材料的数量。甲方应按时提供乙方需要的材料。
甲方负责采购供应的材料应符合设计要求的合格产品,并应按时供应到现场,甲乙方应办理交接手续。乙方如发现甲方提供的材料有质量问题或规格差异,应及时向甲方提出,甲方仍表示使用的,由此造成工程损失,责任由甲方承担。 乙方自带施工的必须工具(锥子、切割片等),要保证安全性、良好使用性,乙方自行承担工具维修费和损耗费用。
第三条 有关安全生产和防火等的现场管理约定:
1、严格遵守规定的装饰装修的施工时间,降低施工噪音,减少环境污染,处理好由施工带来的扰民问题及与周围单位、住户的关系。
2、未经甲方同意及有关部门批准,施工中不得随意拆改原建筑物结构及各种设备管线。
3、工程竣工未移交甲方之前,负责对现场的一切设施和工程成品进行保护。
4、乙方施工人员的一切安全问题由乙方自行负责。
5、乙方施工人员必须服从甲方管理员的管理。
第四条 关于工程价款、承包内容、施工工艺、结算的预定:
1、石膏板吊顶 xx元/㎡
2、灯带 xx元/㎡
3、中空密度板造型线条 xx元/m
4、背景墙大芯板打底 xx元/㎡
5、面板柜子 xx元/㎡
6、窗帘盒 xx元/m
7、做假梁 xx元/m(40分以上)
8、包门套 单面 xx元/m 双面 xx元/m
第五条 付款方式
1、对于双包的工种,材料进场甲方预支材料款给乙方
2、按工程进度给于乙方预支工人生活费
3、各工程完工以前付到造价的70%
4、工程竣工(业主验收)付到造价的100%
5、甲方未按工程进度支付的,乙方有权停工
第六条 纠纷处理方式:
因工程质量双方发生争议时,双方协商解决;当事人不愿通过协商、调解解决,或协商、调解不成时,可以按照本合同约定向人民法院提起拆讼。
第七条 符则
1、本合同经甲、乙双方签字(盖单)后生效。
2、本合同签订后工程不得转包。
3、本合同一式两份,甲、乙双方各执一份。
4、合同有效期至
甲方签字(盖单): 乙方签字(盖单):
日期: 日期:
家装木工承包合同范文二
建设单位(甲方):
承包单位(乙方):
甲方有 ,现委托乙方对该卖场 木工工程 部份进行广告装修。该工程所用的材料由甲方负责,乙方按甲方图纸进行施工(附图纸)。
一、工程名称:室内装修 木工 工程
二、施工地点:
三、木工工程总造价:按甲乙双方签订的价格(附价格表、施工验收检准)
四、付款方式:工程完全完工并经业主和甲方项目负责人验收合格后,甲方贰拾天内支付乙方95%的工程款,余下的5%的工程款为质量保证金,甲方需于三个月后支付给乙方。
五、施工期限:从 年 月 日起至 年 月 日止
共 天内完成,如因甲方改变设计方案,或甲方材料不能按时到位,工期将顺延。
六、保修:保修期为 半 年,保修期内属乙方施工质量问题,乙方需进行保修,保修所产生的费用(包括材料)均由乙方负责,或由甲方从质量保证金中扣回;若费用超过质量保证金,甲方有权在乙方的其他工程款中扣回。(如属人为损坏或天然灾害问题,不在保修范围之内)。
七、责任:(1)、乙方在进场施工前需检查墙体结构的完整、对上工序完工的基本验收,并作好验收交接。对接收甲方的材料时应作数量和质量的验收,验收后出现的短缺和损坏由乙方负责。另如发现乙方人员偷取甲方的材料,一经证实将以一罚十处理。
(2)、乙方未经甲方同意不能变更施工方案,否则造成的经济损失由乙方负责。
(3)、施工过程中乙方应注意消防、工伤的安全,严格按照甲方的施工指引进行施工,施工期间由于乙方的原因所造成的意外损失和工伤,由乙方自行负责。
(4)、因乙方的原因未能按工期完成的,按延误天数每天扣罚总工程款的5%.
八、本合同一式两份,甲、乙双方各一份。由双方签字后生效,全部工程结算后自行终止。
九、单价 室外铝塑板招牌 室内基层打底 室内铝塑板 室外铝塑板包柱 甲方: 乙方:
签约代表: 签约代表:
签约日期: 年 月 日 签约日期: 年 月 日
家装木工承包合同范文三
业主(以下简称甲方): 身份证号码: 联系电话:施工方(以下简称乙方): 身份证号码:
联系电话:甲乙双方本着友好合作的态度,按照《民法典》等相关法律,在平等公正的情况下签订合同如下:
一、工程概况
工程地址:
二、价格
木工清包工费:。
三、付款方式
1、施工人进场,预支生活费:
2、其余款根据施工进度分期支付 ,工程完成付
经验收合格,三日内结清其余款项 元。
四、设计
1、甲方须向乙方提供图纸一套,付装修内容明细表,并负责交底工作。
2、甲方若无图纸,须向乙方交代清楚要求,乙方施工前须画草图让甲方认可。
3、如有项目变更,经双方协商,工程相应调整。
五、材料
1、乙方应提前3天向甲方提供需购材料清单,甲方应在3天内及时采购材料供施工方使用,双方应各自承担各自拖延工期的责任和经济损失。
2、未经甲方同意,乙方不得自行采购材料,若已采购,甲方有权无条件拒绝使用并可拒绝支付材料的费用。
3、乙方应帮甲方收货,核对数量和配件的准确性。
4、乙方应保证施工期间在本小区内没有双包和半包的工程。
5、乙方应做好对施工完成的成品和甲方所提供的材料、设备的保管工作,禁止闲杂人等进入现场。由于乙方保管或安装不当造成损失的,应由乙方负责赔偿。
6、未经甲方许可,乙方不得携带任何建材出门,若发现此类现象,按材料价格的3倍从人工费中扣除。
六、工期
从 年 月 日起至 年 月 日止,工期为 天,因甲方因素拖延,工期顺延,因乙方因素拖延工期,甲方可相应扣除乙方的装修费。
七、材料搬运
甲方材料送至工程所在地,乙方施工人员应无条件协助搬运。
八、垃圾清运
1、垃圾袋装化,垃圾应日日清。
2、垃圾应由乙方清运至物业指定的垃圾堆放场所。
九、劳动力管理
1、开工前乙方应向甲方提供所有施工人员的身份证复印件。
2、未经甲方许可,所有人员不得在施工现场过夜。
3、甲方应及时替乙方办理小区出入证件并支付相关费用。
4、在合同价内,乙方应提供数人次跟随甲方挑选材料。
5、乙方未经甲方同意不得任意条换施工人员,每天工地必须保持人以上的施工人员。
6、未经甲方同意,任何情况下乙方不得停工或殆工。不得将工程转包他人。
十、施工机具
乙方自带施工所需工具,并保证工具的安全性和良好使用性,乙方自行承担工具的维修费。
十一、工地现场管理
1、 现场禁止使用明火,现场禁止吸烟。
2、 油漆材料必须和其他材料分开放置。
十二、维修
1、 因乙方施工原因导致的质量问题,乙方应在甲方通知乙方后3天内及时维修。
2、 若乙方未能按合同及时完成维修,甲方可以安排其他施工队进行维修工作,所产生的费用按实从装修费中扣除。
十三、合同附件
1、 施工项目清单及明细表。
十四、合同争议
出现争议甲乙双方友好协商解决,协商不成可向争议所在地法院提起诉讼。
十五、装修要求
a,包门套、窗套、腰线、角线、柱边、吊棚、石膏线等
1、门、窗套线宽不大于3mm,厚度不大于3mm。
2、要求横平竖直,2米内1mm每工件外露部分倒角1x45,所有阴阳脚都要靠角尺。
3、垂直贴在门套上检查垂直度。
4、注意所有门要等高等宽。
b,储物柜:木工板低架、实木线收口,内部有隔断,(多组,见详细图纸)。壁柜验收要求:
1、 要求横平竖直,2米内1mm,每工件外漏部分倒角1x45,所有阴阳脚都要考角尺。 c,厨房橱柜:
1、 提前咨询柜体内水管布置。
d,其他说明要求:
1、 保证原先商定好的装潢设计思想,不能擅自改动。如有变化,必须征得业主同意。
2、 业主购买的柜门、房门、包括所购的材料、设备等协助搬运至现场及安装。
3、 除上述装潢要求外,如有增加或改动工作,不超过工程的10%,不增加工资。
4、 工程为清包,业主者提供材料。施工工具等设备由施工承包人自备自理。
5、 施工方必须保证施工质量,发生施工质量问题,施工方应及时予以改正。竣工验收时发
现质量问题,施工方应立即予以改正,在未达到业主的整改要求前业主有权拒付人工费
6、 施工人员要文明施工,爱护室内原有设施,禁止野蛮施工。业主所有物品未经许可,不
得擅自处理。业主对表现不好的施工人员有权要求掉换,承包人不得拖延。
7、 施工方负责及时清理建筑垃圾,工程施工结束后,施工人员负责场内建筑垃圾清运。
8、 承包人应加强对现场施工人员防火防盗安全教育,如违反操作规程发生安全事故,承包人自行负责,如对业主造成损失要进行赔偿。施工人员不得在施工现场违法乱纪,一旦发生问题,后果自负。
甲方:(签章) 乙方:(签章)
签约日期: 签约日期:
甲方:____________________ (以下简称甲方)
乙方: ____________________(以下简称乙方)
根据《中华人民共和国合同法》和《建筑法》及有关法律法规规定,甲乙双方遵循平等、自愿、公平和诚实信用的原则,就“三辰·国际花园”5#楼地温中央空调安装工程项目事宜,经双方协商一致,签订本合同,以资公共遵守。
第一条 工程概况
1、工程名称: ____________________
2、工程地点:____________________
3、工程范围和内容:工程范围是____________________住宅楼, 共计____________________户;工程内容是地温中央空调正常运行需要的所有设备,包括主机、水井、生活热水、分户计量系统和住宅室内外所有管道和末端产品。前期配合土建所有预埋管件、线盒、套管的施工。
第二条 工程期限
1、本土木安装工程承包合同总工期为:自主体工程开始至主体工程结束验收合格后 ______________个月完工。
2、如遇下列情况,经甲方现场监理工程师或工程师代表签证后,工期作相应顺延,顺延事由结束后则顺延期限届满。但双方约定了顺延期限的,按约定执行。
(1)甲方在合同规定开工日期前10天,不能向乙方交付施工图纸等技术资料,或不能提供符合施工条件的施工场地、进场道路、施工用水、电源,影响乙方进场施工的。
(2)不属包干系数范围内的重大设计变更;施工方法与设计规定不符而增加工程量影响进度者。
(3)在施工中因停水、停电连续影响8小时以上者。
(4)甲方现场监理工程师或工程师代表无故拖延办理签证手续而影响下一工序施工者;或拒绝在乙方送达的文件的签收单上签字,致使乙方无法继续工作。
(5)甲方未按合同规定拨付预付款、工程进度款、代购材料价差款而影响施工进度者。
(6)因遇人力不可抗拒的自然灾害(如台风、水灾、自然原因发生的火灾、地震等)而影响工程进度者。
第三条 工程合同总价
1、本工程合同总价为总住宅建筑面积 ______________㎡* (______________元/㎡),计______________人民币(¥______________)。本价格为初估价格,最终合同总价为住宅主体工程验收后实际建筑面积______________ ㎡*(______________元/㎡),此价包括:中央空调主机、室内外各种管网、生活热水、分户计量系统及所有工程施工中所发生的费用。
2、如遇下列情况,合同总价作相应调整:
(1)合同总价内经双方确认的暂估价变化;
(2)设计发生重大变更;
(3)在施工中新增加了工程项目;
第四条 材料、设备供应
1、本工程所需的空调主机、末端设备和安装材料等物资由乙方负责制作、生产或采购,空调主机、末端设备和控制系统必须是 空调有限公司生产的。
2、材料、设备的检验:
(1)本工程所需材料、设备均由乙方组织供应。
(2)所有材料设备、成品、半成品均应附有合格证,都要由甲方或甲方指定的监理工程师检查验收,签署物资验收合格单后方可进场。已进场的物资未经甲方许可并签署出场证书,不得运出场外。
(3)已进场的物资,若发现有不合格者,负责供应该物资的一方必须迅速将其运出场外。
(4)具有合格证书的材料、设备,任何一方如有异议要求检验时,可以重新检验,检验后如属合格产品,其检验费用由要求检验的一方承担;如属不合格产品,检验费用由供料一方负担。
(5)没有合格证书,且未经试验鉴定或经过试验鉴定为不合格的材料、设备和构配件等,不得用于本工程。若属材料人员失职或其它原因造成不良后果,由责任一方负责。
(6)任何一方强迫对方使用不合格的材料、设备和构配件于本工程的,都要签证记录在案,由此引起的一切后果由强迫一方负责。
第五条 工程质量和检查验收
1、乙方向甲方提供施工图纸2套,以利甲方施工监督,乙方必须严格按施工图纸、说明文件和国家颁发的有关规范、规程进行施工,地温中央空调所使用的地下水必须经有相关资质的单位探明地下水资源并提交正式报告4份。以利于确定水井的最终深度,确保地温中央空调长期正常使用。
2、甲方聘用的现场监理工程师或工程师代表,必须以书面形式向乙方通知其姓名、身份、所承担的任务、工作权限。授权不明的,视为享有全权,甲方应当为其在工程中的一切行为承担全部责任。
3、乙方必须以书面形式将施工现场负责人、技术负责人及其它管理人员的姓名、身份、工作职责和权限通知甲方现场工程师或监理工程师。
4、乙方应按工程进度,及时提供关于工程质量的技术资料,如材料、设备合格证、试验、试压、测试、报告等的复印件。材料代用必须经过甲方同意并签证后,方可使用。
5、隐蔽工程由乙方自检后,填写《隐蔽工程验收单》通知甲方现场监理工程师或工程师代表检查验收,监理工程师接到通知后2小时内应到现场检验,认可签证后,方可进行下一步工序施工。监理工程师未及时检查验收,乙方经质量检查部门检验确认合格后,也可隐蔽继续施工,甲方应予承认并办理检验合格手续。如提出异议,经复查合格后,其费用由甲方负责;不合格者,由乙方负责,因此而造成工期损失由责任方负责。
6、安装完成后,由乙方负责试车或调试。试车或调试中需要的动力、燃料、油料、材料、仪器、专用工具、技术劳务费用及在施工中与其他单位所发生的配合、协调费用均由乙方承担。
7、工程竣工验收,应以施工图纸、图说、技术交底纪要、设计变更通知、国家颁发的施工验收规范和质量检验标准为依据。
8、工程竣工后,乙方按规定整理提供完整的技术档案资料,并向甲方发出竣工通知书,经双方协商确定验收时间,由甲方在20日内组织有关单位进行竣工验收。
9、验收合格后,双方应在5日内签署交工验收证书,并在15日将工程移交给甲方管理,如甲方在 15 天内未派人接收,其保管费用和造成的损失由甲方承担。本工程正式安装工期为主体验收合格 个月,超过一天罚款伍佰元,依次类推。
10、已竣工未验收工程,在交工前由乙方负责保管,甲方不得动用,若甲方已经使用,即视为交验。
11、工程交工验收后,保修期为1年,自竣工验收合格后第16天开始计算。保修证书在交工验收后由乙方填写交给甲方。
12、由施工造成的工程质量问题,甲方应书面通知乙方并约定时间进行修理。在保修期内乙方拒不修理或通知后6小时不到的,甲方可动用预留保修款自行请人修理,费用从保修金中扣除。
13、工程质量及售后服务承诺
(1)对所有产品设备免费提供终身维护、终身技术咨询服务。
(2)中央空调系统所有设备保修期为1年,保修期内因制造自身质量而发生的损坏或不能正常运行,由乙方免费提供维修或更换服务。保修期外,终生免费维修,在更换配件时由乙方以最优惠价格提供,并保证价格不高于市场同类商品价格。
(3)中央空调系统末端产品出现故障30分钟内赶到现场,1小时内解决问题。
(4)中央空调设备(包括主机、潜水泵、主管道等)出现故障2小时内赶到,8小时内解决问题。
(5)乙方在每年春秋两季免费为中央空调系统检修2次。 第六条 施工设计变更
1、乙方交付的设计图纸、说明和有关技术资料,均为施工的有效依据,甲方、乙方均不得擅自修改。
2、施工图的重大修改变更,必须经原批准、设计单位同意,并于修改前2天办理设计修改议定单。设计修改议定单经甲方签证后,乙方才予实施。议定单和修改图纸发出份数与施工图份数相同,并作为合同的补充文件。
3、当修改图纸属于设计错误、设备变更、施工面积(容积)增加、结构改变、标准过高、工艺变化、地质条件与设计不符实际时,其增加的费用(包括返工损失、停工、窝工、人员和机械设备调迁,材料、构配件积压的实际损失)由责任方负责并调整合同造价。
4、乙方在保证工程质量和不降低设计标准的前提下,提出修改设计的合理化建议,经甲方、设计单位或有关技术部门同意后可以实施。
5、任何设计或工程变更经过确认后,涉及工程造价变更的,双方应当签订书面变更协议,协议书经双方现场工程师签字后生效。授权书明确规定工程师没有变更签字权的,协议书还必须加盖该方的印章方为有效。
第七条 双方负责事项
1、甲方
(1)甲方负责三通一平,乙方必须自备合格的水电计量表。
(2)根据施工地区供水、供电、水压、电压情况,采取措施满足施工用水、用电的需要。
(3)确定管道等设施的定位标桩、水准点和坐标控制点。
(4)组织承发包双方和设计单位参加的施工图纸交底,并做好三方签署的交底纪要,并在5天内分送有关单位。
(5)审核乙方工程进度月报,及时向乙方支付工程进度款。
(6)派驻施工现场的监理工程师或工程师代表,对工程进度、工程质量、隐蔽工程和合同执行进行监督检查,负责设计图纸问题的处理,负责设计变更的签证,工程中间验收、工程进度拨款签证和其它必须的签证;负责签收乙方送达的各项文件。
(7)组织对工程的竣工验收,并按合同规定日期配合乙方办好决算工作,及时了结工程尾款。
2、乙方
(1)编制施工组织设计(或施工方案),施工总进度计划、材料设备、成品、半成品等进场计划,用水、用电计划、开竣工通知书、隐蔽工程验收单等。
(2)按双方商定的分工范围,做好材料和设备的采购、供应和管理。
(3)于每月底前2天向甲方报送月度施工计划。
(4)严格按照施工图与说明书进行施工,确保工程质量,按合同规定的时间如期完工和交付。
(5)已安装的设备,在交工前应负责保管,并清理好场地。
(6)提供竣工验收技术资料,办理工程竣工结算,参加竣工验收。
(7)在合同规定的保修期内,乙方负责无偿维修。
第八条 工程价款的结算与支付
1、除实行一次性包死的固定价格外,乙方在工程竣工后 ______________天内,将竣工结算文件送交甲方审查,甲方在接到结算文件天内审查完毕。
2、工程款支付方法和时间:本合同签订后 ______________日内,甲方向乙方支付合同总价______________%的预付款,计人民币______________元。室内管道材料和末端产品(风机盘算、控制开关)到达施工现场,经甲方人员验收合格后,甲方向乙方支付合同价______________ %的预付款,计人民币______________元。中央空调主机到达施工现场,经甲方人员验收合格后,甲方向乙方支付合同总价 ______________%的预付款,计人民币______________元。中央空调工程全部竣工,经双方验收合格签字后支付剩余工程款(除合同总价______________%的保修金)。中央空调保修期一年,保修金为合同总价的 ______________%,保修金待保修期满,甲方确认无质量问题后______________天内一次性支付给乙方。
3、甲方结算工程款,应当通过银行转账结算。除非乙方出具要求支付现金的书面通知,甲方不得在现场支付现金。
第九条 争议的解决方式
合同执行过程中如发生争议,双方应及时协商解决。协商不成时,由合同签订所在地人民法院裁判解决。
第十条 特殊条款
本合同条款如对特殊情况有未尽事宜,双方可根据具体情况结合有关规定议定特殊条款。
第十一条 附则
1、本合同履行中,双方以传真、信函、电报、电子邮件等载体向对方发出的指令、通知、签证、结算书等,对方在收到后必须按通知要求进行签收,否则,也视为违约。
2、本合同履行中乙方发给甲方或第三方的有关变更、授权、验收、结算的文书、函件、必须加盖乙方公章方可有效。
3、本合同其它未言明事项,一律按《中华人民共和国合同法》和国务院、建设部有关行政法规、规章规定执行。
5、本合同正本肆份,其中甲方执贰份,乙方执贰份。
甲方(公章): __________________乙方(公章):__________________
法定代表人:__________________ 法定代表人:__________________
日 期: __________________日 期: __________________
发包单位: 简称甲方 承包单位: 简称乙方 根据甲乙双方协商同意将 模板分部 工程发包给乙方,按本工程实际情况签订施工协议书,具体条文如下:一、所属工程承包施工内容1、对木工在施工中的要求: 首先要认真熟悉施工图纸,对项目部所发的变更资料,技术交底,安全交底认真执行; 施工过程中对完成的工程量每天要及时对照规范自检,及时整改,杜绝返工; 有节约材料的指导思想,认真进行模板工程劳务承包协议书的配制及开具租赁材料料单;每个工作面施工完毕剩余材料应及时清理到原堆放地点; 要有文明施工的指导思想,做到材料堆放整齐,拆除后材料不得从楼面往下扔; 每天做到施工用具清理入库,摆放整齐,整个木工区域内有人清扫; 施工中模板拆除后应清理、整修、上脱模剂、分类堆放到指定地点,保持场面道路畅通; 在整个施工过程中,木工班长始终在现场,进行协调工作,始终有负责技术的管理人员在现场配合项目部进行质量及安全检查和监督管理,乙方木工班长是 、技术管理员是 ; 在整个施工过程中,所有材料需用井字架、塔吊进行垂直运输的应听从项目部的安排,不得自行操作; 配合其他工程的工作,如配合水电工的墙、地面的留洞、留槽等; 爱护甲方提供的安全防护设施,对有安全隐患的部位应停止作业,及时通知项目部采取措施消除隐患;2、甲方仅提供乙方以下工具:a)翻斗车b)板车c)塔吊d)井架e)高凳f)跳板。 由乙方自带和采购的小型机具、安全帽(带)及劳保用品。如安全帽(带)、雨衣、胶鞋、手套、灰桶、洋锹、洋镐、墙线、凿子、郎头、扫帚等所有除甲方提供施工机具外用木工必须自带所有施工机械,包括混凝土表面的打磨机械和凿混凝土的工具及用品。二、工期要求:1、开工日期按甲方签证的开工日期________年____月____日为准。2、总工期为 天,竣工日期________年____月____日。 具体施工进度根据甲方所安排的进度计划严格执行如期完成。从浇砼垫层开工期:c:____日历天;b:____日历天;a:____日历天。三、总的施工要求: 依照本工程施工图,施工说明书及变更、按国家建委颁发的建筑安装工程验收规范及有关补充规定执行,具体验收规范及有关补充规定执行。四、进度质量奖罚:1、甲方现场安排总进度计划,进度不能如期完成,每延期一天罚款 100 元,周进度计划,每延期一天罚款 100 元。2、本工程主体模板分项必须确保优质主体结构,如模板分部达不到优质主体,主体扣除 2 元2,主体验收作一次评价。3、在施工过程中发现质量问题必须及时返工重做,以返工材料价格五倍赔偿。4、工程中所有的质量、安全、文明施工等问题,现场施工员有权做出处罚,罚款在生活费或工资款中扣除。五、安全达标要求: 本工程在施工过程中必须严格按照国家颁布的建筑安全技术操作规程施工。六、工程中所用的建筑材料全部由甲方供应到工地现场,如发生材料不能及时供应,脱节由甲、乙双方共同协商办理停工签证手续。七、各工程承包价格如下(1) c厂房 元㎡、b厂房 元㎡ 主体结构达到优质;不粉刷按c厂房 元㎡、b厂房 元㎡ 结算 。a厂房暂定由乙方施工,如b、c厂房施工质量达不到优质主体,甲方有权另行发包给其它班组。a厂模板承包价为 元㎡,质量及其它各方面做得较好将另行奖励0.5~1元㎡;做不好时扣0.5~1元㎡。(2)以上分部工程,甲方根据实际情况有权另行安排其他队伍施工,施工的每分部单价按以上单价在总价内扣除。(3)在每一分部工程施工前甲、乙双方必须另签施工协议,如分部不签施工协议,该分部不得清帐。2、生活费发放按甲方所排工程进度发放,具体每月生活费发放金额按每月各工种实际出勤施工人数,按 15 元天计算,生活费发放必须经过现场管理人员签字后报项目经理部审批。人工工资在春节之前付已完成工作量的70%以上,余款________年内结清。3、工程竣工后,余款待________年内逐步付清。九、社会综合治理:1、所有参加施工人员必须具有身体证并办理所需办理的一切证件,服从一切管理规定。2、住宿文明、集体宿舍内严禁男女混合居住,发现一次罚款1000元,严禁违章计划生育人员在宿舍住宿或做工。3、甲方提供施工人员集体宿舍居住,任何施工人员一律不准搬进新盖楼房居住,发现一次罚款500元。4、接电源,烧电饭煲、电炒锅、电炉等,发现一次罚款500元。5、生活区内食堂不得自行烧饭烧菜,饭盒统一编号,食堂应清洁无蚊蝇。按甲方卫生要求统一蒸饭、烧菜分工种自行负责,服从项目部统一指挥,乙方安排卫生员负责生活区、食堂、厕所等卫生工作。6、本工程总包价包括就业费、暂住证费及卫生防疫证费用。十、现场文明管理:1、所有施工人员进入施工管理必须戴好安全帽、系好安全带、严禁穿拖鞋赤膊。2、现场保持整洁,所有建筑垃圾及时处理干净,做到工完料净,临时施工道路每日清扫。3、施工机械完工后应清洗干净、上油,所有工具归纳到指定位置,小车摆放整齐,配电箱专人上锁保管钥匙,井字架由专人开完工后拉切断电源,以上每发现一次不按要求,罚款100元次。4、各班组使用电动机械如雨淋和人为造成损坏要该班组承担责任,修理费用赔偿。5、在本地上每发生一次打架行为罚款每人500元,情况严重甲方有权移交公安机关处理并令其离开本工地。6、各工种负责把自己工种材料堆放整齐、清理干净。7、工地现场文明施工及材料的浪费,按现场施工负责人要求进行罚款。浪费材料按材料费的五倍罚款。 十一、其它:1、途中违约按完成工作量的60%付款,三天之内人员全部撤离工地。甲方重新安排施工队伍进场,费用由乙方承担,如果独完成主体后违约,其主体工程按总造价的60%计算。2、本协议甲乙双方慎照执行,一式四份,承包方执一份,双方签字后生效。3、其它未尽事宜,双方协商解决。 甲方签字(盖章): 乙方签字(盖章):________年____月____日________年____月____日 包木工承包合同范本二 甲方: (简称:甲方) 乙方: (简称:乙方) 经甲乙双方共同协商,甲方将 项目 工程以包工,包制模,铁钉,铁线,电缆,电锯电片及机械所有的电缆电线工具,包图纸上木工制安及所有木工工程一次性承包给乙方施工,为安全保质保量金,工程结束后给予返还。 一,承包单价;乙方所承包的木工工程,其单价按建筑面积的( )元㎡(包括基础地下室设施及屋顶斜屋面型线条主体),按此单价为最终结算价,甲方不另追加乙方任何费用,面积计算以图纸为准。 二,承包范围;乙方按设计图纸,设计变更完成该工程所有的木工工程,(含附属零星工程木工及基础设施的制安,负责工程完工后,所有的模板,方条,顶木,步步紧,方条等的清理及按甲方要求制定的地方分类堆放好)。 三,乙方负责:1.乙方应付责组织本工程所需要的熟练工人,机械工具辅助材料,熟悉施工图纸规格按照设计图纸施工规范及安全生产条列,进度计划国家品质标准施工。2.服从项目管理人员及施工员统一指挥,调配和检查,遵守项目人员制定的各项规章制度,不准随意浪费甲方原材料,如发现乙方随意浪费,甲方有权要求乙方按原价加倍赔偿。3.乙方不得在工地上无理取闹不服从甲方现场管理人员统一指挥调度及阻止别的施工班组施工的,发现一次罚款500元,累次不改甲方有权单方面终止合同,乙方按实际完成工程量的60%结算,并自动退场。4.主体施工过程中,乙方应按时,按质,按量完成施工任务。不准有爆木。漏浆现象,发现有出以每处50200元罚款,并即时处理,因木工验收不合格造成返工,甲方有权要求乙方加倍赔偿一切浪费的原材料及需别的施工班组配合返工所需人工工资,工程所有爆木,漏浆处,乙方应及时处理掉。尾期工程中需要制安的应随叫随到,不到的话,甲方有权请他人做,其工资按市场价格双倍从乙方未付工程款中扣除,影响工期的按合同规定处罚,乙方应无异议。 四,甲方负责;1.负责对乙方的图纸技术交底及安全三级教育,指导,检查乙方施工过程中的施工质量。2.按合同约定按时支付工程款。3.无偿提供乙方的住宿及生活用水用电,(不含电磁炉用电) 五,工期要求;1.乙方应严格按照项目部制定的各项施工进度计划进行施工,具体进度计划按项目部制定的施工进度计划。2.乙方不能按甲方进度计划完成工期内的工程量时,甲方有权高价在外面请人帮忙完成,乙方无权阻扰,其工资从乙方工程进度款中扣取,工期拖延一天处以xxx元的工期处罚金,按工期计划乙方提前完成应给与奖励。3.因乙方原因造成工程停工三天以上,甲方有权单方面终止合同另找施工队,结算按实际完成工程量的60%结算,结算时间按工程主体全部封顶后结算,余下的部分作为重组新班组和甲方的损失费用。 六;质量标准; 规格按照施工图纸设计变更通知及现行的国家有关强制性规范规定施工,并达到国家工程品质验收合格标准,如有返工给甲方造成材料浪费或延误工期的,甲方有权追究其赔偿责任并罚款,费用从乙方工资中扣回。 七,安全要求;1.乙方工人进入施工现场都必须遵守安全操作规程,佩戴安全帽,穿工作服,穿胶鞋上班。2.上班时间不许喝酒,打闹,严格安全生产条例方针,及项目部组织所要求的安全知识讲座内容交底,进行施工。3.如乙方在施工过程所造成的任何安全事故,由乙方负全部责任和费用及事后处理,与甲方无关。4.不带安全帽,穿拖鞋,喝酒上班的发现一次每人每次30元罚款,此款从工资中扣除,并通报批评,现场严禁带小孩或社会闲杂人员进入工地,住宿,逗留。 八,付款方式;本工程第一次按工程总量的三楼付款80%,然后按月进度工程量的80%付款。余款在完成承包内工作后两个月内结清。 九,本合同未尽事宜,双方可根据情况随时协商补充,补充协议与本合同具有同等效力。 十,本合同书自签字之日起生效,工程竣工,工程款全部结清后本民法典律效力自行终止。 十一,本协议一式两份,双方各持一份,同时具有相应法律效力。 甲方(签章) 乙方(签章) 二________年____月____日 二________年____月____日返
甲方:____________________________
乙方:____________________________
根据施工需要,甲方将
工程以包工不包料方式分包给乙方进行施工。
为便于班组间施工作业的交叉管理,明确双方在履约过程中的权利、责任、义务,确保分项工程施工质量,加强施工进度的控制,保证工程顺利进行,经双方共同协商订立如下合同,双方共同遵照执行。
一、工程名称:______________
二、工程地点:______________
三、承包范围:施工图纸范围以内框架主体的模板工程的所有施工内容,施工过程中(含施工前)的一切图纸变更,技术更改随变,已包在承包范围以内。
四、工程内容:模板制作、安装、模板拆除、清理分类堆放、板面清理、板缝隙密封处理、起钉子等一切模板施工工序。
工程完工周转材料清理、分类归堆。
五、工程承包方式:
1、本工程采用包工不包料的形式承包施工(即包人工、包质量、包进度、包安全、包文明施工、包材料节约)。
手提电动工具及手工工具乙方负责。
2、按施工图纸,包括变更等部分模板工程人工费按实际展开面积计价木工装修合同范本木工装修合同范本。
六、质量要求:严格要求按图施工,符合规范要求,质量等级必须满足合格。
1、模板及其支架必须具有足够的刚度、强度和稳定性,其支架的支承部分必须有足够的支承面积。
漏浆由木工班组清理干净,浇砼时木工必须安排专人看模,漏下砼浆用水冲洗干净,否则每次罚款200元。
七、施工工期:乙方施工必须满足流水作业需要,按时完成甲方进度计划安排,且不得因自身原因延误其它班组施工进度。
八、付款方式:______________
九、工程管理双方责任:甲方责任
1、提供有效的施工图纸,处理施工技术问题;2、提供外脚手架及安全防护网;3、负责协调处理施工现场各作业班组交叉作业及其他情况下发生的矛盾问题,尽量避免因配合不到位造成返工、返修,乙方必须服从甲方的处理意见;4、及时将支模用的材料供应至现场;5、负责模板工程质量跟踪检查及质量监督,负责模板分项工程质量评定及验收;6、根据规范、标准、合同及施工图要求,甲方为分项、分部工程质量的最终确认者;7、组织有关人员在拆模后及时对砼表面平整度、垂直度、夹渣漏浆情况等方面进行实测,按现行验收规范及评定标准进行质量评定,并以实际评定结果作为对乙方模板安装质量的奖罚依据;8、提供施工用水、用电及夜间施工照明和工人现场临时住宿;9、按合同约定进度支付工程款。
乙方责任
1、施工前,必须熟悉图纸,对工人进行安全技术交底,所有工人必须是熟练工人,特殊工种操作必须持证上岗。
遵守法规和甲方的各项规章制度、管理条例,服从甲方施工管理人员指挥,不得以任何理由为难甲方人员;2、熟悉图纸,按图纸要求提前配好模板,尽量减少余料;3、在施工过程中发现图纸设计问题,及时向甲方工长汇报,不得擅自更改设计;4、甲方提供的大件施工工具、机械等,乙方在使用过程中要注意养护,操作不当和人为造成的损坏要赔偿,所发生的安全事故由乙方负责;5、按图纸及工艺要求提前做好材料计划,报甲方工长审批;6、乙方必须严格遵守安全技术操作规程及有关安全法规,造成的安全事故责任由乙方承担;6、文明施工,做好施工组织、管理,切实做到工完场地清、模板起钉、材料分类归拢,堆放整齐有序。
特别要注意检查柱头、梁沟等,务必清理干净;7、提前安排好浇砼期间的木工值班工作,浇砼过程中要经常检查,如发现有变形、松动等现象要及时修补加固;8、因质量不合格或其他过失造成的返工,属于乙方责任的,乙方应承担由此引起的工机料损失。
9、协调好流水作业相关班组的工作程序,不得故意刁难;10、工地内不得闹事生非,不得中伤他人、打架,各项违法活动一经发现处100元罚款,情节严重者扭送公安机关处理。
11、合理使用模板,未经主管工长同意不得随意切割成形大块模板,违者视其情节轻重每次罚款200元以上12、本工程乙方和第三方签的任何协议、合同,属乙方自已责任,与甲方无关,甲方不予认可木工装修合同范本合同范本。
13、施工过程中本班工人因自已原因或违章出现的一切安全事故(含第三者)均由乙方负责全部责任。
14、甲方严格禁止乙方擅自拆、改、移动配电设施,以及损失配电设施的行为及违反安全用电的行为,发生一切后果由乙方承担。
15、甲方严格禁止乙方擅自拆、改、移动安全防护设施、以及损坏安全防护设施的行为及违反安全操作的行为,发生一切后果由乙方承担。
16、进入施工现场不按规定使用安全帽和安全带,甲方责令未改者,处以50元罚款。
甲方:___________乙方:___________
____年_____月_____日
part工general conditions
第一章 总则
definitions and interpretation
定义和释义
1.(1)in the contract,as hereinafter defined,the following words and expressions shall have the meanings hereby assigned to them,except where the context otherwise requires:
1.1在本合同中,除按上下文另具意义者外,下列词语应解释如下:
(a)'employer' means the party named in part ii who will employ the contractor and the legal successors in title to the employer,but not,except with the consent of the contractor,any assignee of the employer.
“业主”指第二章中所指定的雇用承包人的一方或其权利 继承人 ,但不包括业主的受让人,经承包人同意者除外。
(b)“contractor”means the person or persons,firm or company whose tender has been accepted by the employerand includes the contractor’s personal representatives,successors and permitted assigns.
“承包人”指标书已被业主接受的某个或某些人、商行或公司,包括其个人代表,继承人和业经认可的受让人。
(c)“engineer”means the engineer designated as such in part ii,or other engineer appointed from time to time by the employer and notified in writing to the contractor to act as engineer for the purposes of the contract in place of the engineer、designated.
“工程师”指第二章中所指定的工程师,或由业主随时任命且书面通知承包人以代替指定工程师履行合同职责的其他工程师。
(d) 'engineer’s representative' means any resident engineer or assistant of the engineer or any clerk of works appointed from time to time by the employer or the engineer to perform the duties set forth in clause 2 hereof,whose authority shall be notified in writing to the contractor by the engineer.
“工程师代表”指任何常驻工程技术人员、工程师助手,或由业主或工程师随时任命履行本合同第二条规定职责的任何工程现场监督,其权限应由工程师书面通告承包人。
(e) “works” shall include both permanent works and temporary works,
“工程”包括永久性工程和临建工程。
(f)“contract” means the conditions of contract,specification,drawings,priced bill of quantities,schedule of rates and prices,if any,tender,letter of acceptance and the contract agreement,if completed.
“合同”指合同条款、技术规范、图纸、标价的建筑工程清单、单价和价格表(如果有),还可指标书、接受证书以及承包协议(如已完成)。
(g) “contract price” means the sum named in the letter of acceptance, subject to such additions thereto or deductions therefrom as may be made under the provisions hereinafter contained.
“合同价格”指在接受证书中确定的数额,可按本合同以下条款规定增减。
(h)“constructional plant' means all appliances or things of whatsoever nature required in or about the execution or maintenance of the works but does not include materials or other things intended to form or forming part of the permanent works.
“建筑设备”指工程施工和维修中或有关施工和维修所需的全部设备或物品,不论任何性质,但不包括旨在构成或正在构成永久性工程某一部分的材料或其他物品。
(i)“temporary works' means all temporary works of every kind required in or about the execution or maintenance of the works.
“临建工程”指工程施工或维修或有关工程施工或维修所需的各种 临时工 程。
(j)“permanent works”means the permanent works to be executed and maintained in accordance with the contract.
“永久性工程”指按合同将施工和维修的永久工程。
(k) “specification” means the specification referred to in the tender and any modification thereof or addition thereto as may from time to time be furnished or approved in writing by the engineer.
“技术规范”指在标书或任何标书更改中提及的规范,或由工程师随时可能增加或书面同意增加的部分。
(1)“drawings” means the drawings referred to in the specification and any modification of such drawings approved in writing by the engineer and such other drawings as may from time to time be furnished or approved in writing by the engineer.
“图纸”指技术规范中规定的图纸,经工程师书面同意对此种图纸所作的任何更改,以及可由工程师随时提供或书面认同的其他图纸。
(m) “site” means the land and other places on,under,in or through which the permanent works or temporary works designed by the engineer are to be executed and any other lands and places provided by the employer for working space or any other purpose as may be apecifically designated in the contract as forming part of the site.
“工地”指工程师设计的永久性或临建工程施工所需的土地及其他场地,包括地面、地下、在之上或通过部分,以及由业主所提供的用作临时储存或其他目的的其他土地或场所,只要能按合同明文规定构成工地的组成部分。
(n)“approved” means approved in writing,including subsequent written confirmation ofprevious verbalapproval and“approval' means approval in writing,including as aforesaid.
“业经认可”指已经经书面认可,包括过后对口头认可的书面确认,“认可”指书面认可,包括上述规定在内。
(2)words importing the singular only also include the plural and vice versa where the context requires·
1.2按合同上下文所需,单数含义的单词也可具有复数的含义,反之一样。
(3)the headings and marginal notes in these conditions of contract shall not be deemed to be part thereof or be taken into consideration in the interpretation or construction thereof or of the contract.
1.3合同条款的标题和边注不得视为合同的一部分,不得用于考虑解释条款或合同。
(4)the word“cost' shall be deemed to include overhead costs whether on or off the site.
1.4“费用”一词应视为含工地上或以外发生的间接费用。
engineer and engineer’s reprf.sfntative
工程师及工程师代表
2.(1)the engineer shall carry out such duties in issuing decisions,certificates and orders as are specified in the contract.in the event of the engineer being required in terms of his appointment by the employer to obtain the specific approval of the employer for the execution of any part of these duties,this shall be set out in part ii of these conditions.
2.1工程师必须按合同明文规定,履行作决断、颁发证书和发出指令等职责。如业主签发的工程师任命书中规定其某些职责的履行得经业主专门认可,其要件应在本合同第二部分予以规定。
(2)the engineer may from time to time in writing delegate to the engineer's representative any of the powers and authorities vested in the engineer and shall furnish to the contractor and to the employer a copy of all such written delegations of powers and authorities. any written instruction or approval given by the engineer’s representative to the contractor within the terms of such delegation,but not otherwise,shall bind the contractor and the employer as though it had been given by the engineer.provided always as follws:
2.2工程师可随时书面授权其代表代行其任何职权,但必须将所有此种授权书的副本提交给承包人和业主。在授权期间,工程师代表给承包人的任何书面指令或认可(仅限于此)对承包人和业主具有与工程师的指令或认可同样的效力。以下规定属于例外:
(a) failure of the engineer's representative to disapprove any work or materials shall not prejudice the power of the engineer thereafter to disapprove such work or materials and to order the pulling down,removal or breaking up thereof.
工程师代表对任何工程或材料的不予否认,不得影响工程师此后否认以及命令拆毁、移动或拆除此种工程或材料的权力。
(b)if the contractor shall be dissatisfied by reason of any decisions of the engineer's representative he shall be entitled to refer the matter to the engineer,who shall thereupon confirm,reverse or vary such decision.
若承包人对工程师代表的任何决定不满意,其有权将此决定提交工程师确认、取消或更改。
assignment and sub—letting
转让和分包
3.the contractor shall not assign the contract or any part thereof,or any benefit or interest therein or thereunder,otherwise than by a charge in favor of the contractor's bankers of any monies due or to become due under this contract,without the prior written consent of the employer.
3.未经业主事前书面同意,承包人不得将合同或其他任何部分,或合同所规定或依合同而产生的任何收益转让,向承包人的开户银行支付按本合同规定到期或即将到期的款项除外。
4.the contractor shall not sub-let the whole of the works.except where otherwise provided by the contract,the contractor shall not sub-let any part of the works without the prior written consent of the engineer,which shall not be unreasonably withheld,and such consent,if given,shall not relieve the(contractor from any liability or obligation under the contract and he shall be responsible for the acts,defaults and neglects of any sub-contractor,his agents,servants or workmen as fully as if they were the acts,defaults or neglects of the contractor,his agents. servants or workmen.provided always that the provision of labor on a piecework basis shall not be deemed to be a subletting under the clause.
4.承包人不得转包整个工程。除非合同另有规定,未经工程师事前书面同意,承包人也不得分包工程的任何部分,但工程师不得无故不同意分包,一旦同意分包,此种同意不得免去承包人所承担的任何合同所规定的责任或义务,他必须对任何分包人、其 代理 人、雇员或工人的行为、不履行和过失负完全责任,如同这些行为、不履行或过失是承包人、其代理人、雇员或工人所为。以计件方式提供劳力不得视为是本条所规定的分包。
contract documents
合同文件
5.(1)there shall be stated in part 1i of these conditions:
5.1以下要件得在合同第二部分规定:
(a)the language or languages in which the contract documents shall be drawn up and.
用以起草合同文件的语言;
(b)the country or state,the law of which is to apply to the contract and according to which
the contract is to be construed.
合同适用哪个国家的法律以及用哪个国家的法律解释合同。
if the said documents are written in more than one language,the language according to which the contract is to be construed and interpreted shall also be designated in part ii,being therein designated the “ruling language”.
如果文件用一种以上语言作成,用以解释合同的语言也必须在第二部分中规定,且将被寇为“主体语言”。
(2)except if and to the extent otherwise provided by the contract,the provisions of the conditions of contract parts ⅰ and ⅱshall prevail over those of any other document forming part of the contract.subject to the foregoing,the several documents forming the contract are to be taken as mutually explanatory of one another,but in case of ambiguities or discrepancies the same shall be explained and adjusted by the engineer who shall thereupon issue to the contractor instructions thereon.provided always that if,in the opinion of the engineer,compliance with any such instructions shall involve the contractor in any cost,which by reason of any such ambiguity or discrepancy could not reasonably have been foreseen by the contractor,the engineer shall certify and the employer shall pay such additional sum as may be reasonable to cover such costs.
5.2除合同中另有规定外,合同第一、二部分的条款规定优于其他任何构成合同的文件的规定。以上述规定为准,构成合同的数个文件可视为能互相解释,如意思含糊或不一致时,由工程师解释和处理,并由此向承包人发出指令。如工程师认为,服从此种指令会使承包人发生额外费用,而此种费用是承包人由于上述意思含糊或不一致而按理无法预见的,工程师应予以证明,业主必须支付相应的额外款额以补偿此种费用。
6.(1)the drawings shall remain in the sole custody of the engineer,but two copies thereof shall be furnished to the contractor free of charge.the contractor shall provide and make at his own expense any further copies required by him.at the completion of the contract the contractor shall return to the engineer all drawings provided under the contract.
6.1图纸由工程师独自保管,但须向承包人免费提供两份副本。承包人所需的其余副本由他自己制作并承担费用。 合同履行 后,承包人须将全部合同图纸归还工程师。
(2)one copy of the drawings,furnished to the contractor as aforesaid,shall be kept by the contractor on the site and the same shall at all reasonable times be available for inspection and use by the engineer and the engineer's representative and by any other person authorized by the engineer in writing.
6.2承包人必须将按上述规定所提交的一份图纸副本留在工地,让工程师及其代表,或工程师书面授权的任何其他人在所有合理的时间内查阅使用。
(3)the contractor shall give written notice to the engineer whenever planning or progress of the works' is likely to be delayed or disrupted unless any further drawing or order,including a direction,instruction or approval,is issued by the engineer within a reasonable time.the notice shall include details of the drawing or order required and of why and by when it is required and of any delay or disruption likely to be suffered if it is late.
6.3如工程师不在适当时间内再提供图纸或命令,包括指示、指令或认可,工程计划或进展便可能被延误或中断时,承包人必须书面通知工程师。通知书中应详细说明所需的图纸或命令,所需原因和时间,以及如果不及时提供而可能造成的任何延误和中断。
(4)if,by reason of any failure or inability of the engineer to issue within a time reasonable in all the circumstances any drawing or order requested by the contractor in accordance with subclause(3)of this clause,the contractor suffers delay and/or incurs costs then the engineer shall take such delay into account in determining any extension of time to which the contractor is entitled under clause 44 hereof and the contractor shall be paid the amount of such cost as shall be reasonable.
6.4如承包人按本条第3款规定索要图纸或命令,由于工程师没有或不能在合理时间内
提供,从而导致承包人误工和左戊承担费用,工程师必须考虑此种延误,以决定是否按本合同第44条规定延长承包人的工期,且只要有理由,承包人所承担的此种费用必须得到补偿。
7.the engineer shall have full power and authority to supply to the contractor from time to time, during the progress of the works,such further drawings and instructions as shall be necessary for the purpose of the proper and adequate execution and maintenance of the works. the contractor shall carry out and be bound by the same.
7.在施工期间,工程师全权负责随时进一步向承包人提供图纸和指示,以满足工程正常施工和维护所需。承包人必须执行且受图纸和指示的约束。
general obligations
总义务
8.(1)the contractor shall,subject to the provisions of the contract,and with due care and diligence, execute and maintain the works and provide all labor,including the supervision thereof, materials,constructional plant and all other things,whether of a temporary or permanent nature,required in and for such execution and maintenance,so far as the necessity for providing the same is specified in or is reasonably to be inferred from the contract.
8.1承包人必须根据合同条款,对工程的施工和维护予以应有的注意,且提供此种施工和维护所必需的包括劳动管理在内的所有劳力、材料、施工成套设备及其他一切物品,不管其是临时或长期性质,只要合同明文规定需要或根据合同合理推断需要。
(2)the contractor shall take full responsibility for the adequacy,stability and safety of all site operations and methods of construction,provided that the contractor shall not be responsible, except as may be expressly provided in the contract,for the design or specification of the permanent works,or for the design or specification of any temporary works prepared by the engineer·
8.2承包人必须对现场操作和施工方法的恰当、稳定及安全性负全部责任。除非合同另有明文规定,承包人对工程师制定的永久性工程的设计或规格,或临建工程的设计或规格概不负责。
9.the contractor shall,when called upon so to do,enter into and execute a contract agreement,to be prepared and completed at the cost of the employer,in the form annexed with such modification as may be necessary,
9.如经要求,承包人必须签署一承包协议,该协议由业主制定并承担费用,协议应附带必要的修正条款。
10.if,for the due performance of the contract,the tender shall contain an undertaking by
the contractor to obtain,when required,a bond or guarantee of an insurance company or bank, or other approved sureties to be jointly and severally bound with the contractor to the employer, in a sum not exceeding that stated in the letter of acceptance for such bond or guarantee,the said insurance company or bank or sureties and the terms of the said bond or guarantee shall be such as shall be approved by the employer. the obtaining of such bond or guarantee or theprovision of such sureties and the cost of the bond or guarantee to be so entered into shall be at the expense in all respects of the contractor,unless the contract otherwise provides.
10.为正常履行合同,在标书中,承包人应承诺按要求取得保险公司或银行的保单或保函,或其他业经认可由承包人向业主负 连带责任 的担保,其数额不超过验收证书中规定的保单或保函额,上述保险公司、银行或担保以及上述保单或保函的条款必须经业主认可。此种保单或保函的取得或担保的提供,以及缔结保单或保函的费用应全部由承包人承担,合同中另有规定的除外。
11.the employer shall have made available to the contractor with the tender documents such data on hydrological and sub-surface conditions as shall have been obtained by or on behalf of the employer from investigations undertaken relevant to the works and the tender shall be deemed to have been based on such data,but the contractor shall be responsible for his own interpretation thereof.
11.业主必须在 招标 文件中向承包人提供由业主或其代理人在进行工程考察时获得的水文及地质情况资料,标书必须视为是基于此种资料所制定的,但承包人必须对资料的理解自行负责。
the contractor shall also be deemed to have inspected and examined the site and its surroundings and information available in connection therewith and to have satisfied himself,so far as is practicable,before submitting his tender,as to the form and nature thereof,including the sub-surface conditions,the hydrological and climatic conditions,the extent and nature of work and materials necessary for the completion of the works,the means of access to the site and the accommodation he may require and,in general,shall be deemed to have obtained all necessary information,subject as above mentioned,as to risks,contingencies and all other circumstances which may influence of affect his tender.
承包人也必须被视为已视察了工地及周围环境,查阅了可获得的有关工地资料,且在提交标书前,对一切实际情况,从形式到性质,包括地质条件、水文和气候条件、工程范围和性质以及完成工程所必需的材料、到达工地的交通工具和所需的食宿等感到满意,总之,承包人必须被视为已得到所有必要的资料,除涉及上述情况外,还涉及风险、意外事件及其他一切可能影响其 投标 的情况。
12.the contractor shall be deemed to have satisfied himself before tendering as to the correctness and sufficiency of his tender for the works and of the rates and prices stated in the priced bill of quantities and the schedule of rates and prices,if any,which tender rates and prices shall,except insofar as it is otherwise provided in the contract,cover all his obligations under the contract and all matters and things necessary for the proper execution and maintenance of the works.if,however,during the execution of the works the contractor shall encounter physical conditions,other than climatic conditions on the site,or artificial obstructions,which conditions or obstructions could,in his opinion,not have been reasonably foreseen by an experienced contractor,the contractor shall forthwith give written notice thereof to the engineer's representative and if,in the opinion of the engineer,such conditions or artificial obstructions could not have been reasonably foreseen by an experienced contractor,then the engineer shall certify and the employer shall pay the additional cost to which the contractor shallhave been put by reason of such conditions,including the proper and reasonable cost.
12.承包人得被视为在投标前已对其工程标书,对标价的建筑工程清单、单价和价格表(如果有)上所列的单价和价格的正确性和完善性感到满意,此种投标价格必须贯穿其所有的合同义务,适用于所有为工程的正常施工和维护所必需的事物,除非本合同另有规定。然而,在施工期间,如承包人遇到除工地气候之外的其他自然情况或人为阻碍,依他所见,此种自然情况或人为阻碍是经验丰富的承包人也无法预见的,承包人必须立即书面通知工程师代表,如工程师确认此种情况或人为阻碍为经验丰富的承包人无法合理预见,工程师必须作证且业主支付承包人由于此种情况而承担的额外费用,包括因遇到此种情况或阻碍而:
(a)of complying with any instruction which the engineer may issue to the contractor in connection therewith,and
(1)为执行工程师可能向承包人发出的与此情况有关的任何指示而发生的正当合理的费用,以及
(b)of any proper and reasonable measures approved by the engineer which the contractor may take in the absence of specific instructions from the engineer.as a result of such conditions or obstructions being encountered.
(2)在无工程师具体指示时,承包人可能采取业经工程师认可的恰当和合理措施而发生的正当合理费用。
13.save insofar as it is legally or physically impossible,the contractor shall execute and maintain the works in strict accordance with the contract to the satisfaction of the engineer and shall comply with and adhere strictly to the engineer's instructions and directions on any matter whether mentioned in the contract or not,touching or concerning the works.the contractor shall take instructions and directions only from the engineer or,subject to the limitations referred to in clause 2 hereof,from the engineer's representative.
13.除因法律或自然因素而不能之外,承包人必须严格按合同规定施工和维护工程,使工程师感到满意,且必须遵守和严格执行工程师有关任何事项的指令和指示,不管合同中是否有规定,提及或涉及到工程,承包人只能从工程师处接受指令和指示,或根据本合同第2条规定,接受工程师代表的指令和指示。
14.(1)within the time stated in part 11 of these conditions,the contractor shall,after the acceptance of his tender,submit to the engineer for his approval a program showing the order of procedure in which he proposes to carry out the works.the contractor shall,whenever required by the engineer or engineers’representative,also provide in writing for his information a general description of the arrangements and methods which the contractor proposes to adopt for the execution of the works.
14.1中标后,承包人得在第二部分条款规定的时间内向工程师提交一份其计划施工的程序方案,以征得工程师的认可。承包人还得随时应工程师或其代表的要求,提供一份承包人的施工计划安排和方法的说明书,以供其参考。
(2)if at any time it should appear to the engineer that the actual progress of the works does not conform to the approved program referred to in sub-clause(1)of this clause,the contractorshall produce,at the request of the engineer,a revised program showing the modifications to the approved program necessary to ensure completion of the works within the time for completion asdefined in clause 48 hereof.
14.2不论何时,只要工程师发现工程实际进度与本条第1款规定的业经认可的方案不符,承包人必须应工程师的要求,提供一份修改方案,对原有的方案作必要的修正,以保证工程能在本合同第48条规定的期限内完工。
(3)the submission to and approval by the engineer or engineer's representative of such programs of the furnishing of such particulars shall not relieve the contractor of any of his duties or responsibilities under the contract.
14.3承包人不得因向工程师或工程师代表提交或经其认可此种方案或因提供此种细节,而被免除任何合同责任或义务。
15.the contractor shall give or provide all necessary super- intendance during the execution of the works and as long thereafter as the engineer may consider necessary for the proper fulfilling of the contractor's obligations under the contract.the contractor,or a competent and authorized agent or representative approved of in writing by the engineer,which approval may at any time be withdrawn,is to be constantly on the works and shall give his whole time to the super-intendance of the same.if such approval shall be withdrawn by the engineer,the contractor shall,as soon as is practicable,having regard to the requirement of replacing him as hereinafter mentioned,after receiving written noticeof suchwithdrawal,remove the agent from the works and shall not thereafter employ him again on the works in any capacity and shall replace him by another agent approved by the engineer.such authorized agent or representative shall receive,on behalf ofthe contractor,directions and instructions from the engineer or, subject to the limitations of clause 2 hereof,the engineer's representative.
15.在施工期间,以及其后在工程师认为是为正常履行合同义务而必需时,承包人必须行使一切监督权。承包人,或其经工程师书面认可的全权代理人或代表(此种认可可随时撤销)应当随时在工地,一直进行监督管理。如工程师撤销对代理人的认可,在接到书面撤销通知后,承包人必须尽快根据撤换规定,将其撤离工地,且今后不得再在工地上以任何身份雇佣他(她),且用另外一位经工程师认可的代理人予以替代。此种授权代理人或代表得代表承包人接受工程师的指令和指示,或按本合同第2条规定,接受工程师代表的指令和指示。
16.(1)the contractor shall provide and employ on the site in connection with the execution and maintenance of the works.
16.1承包人必须在工地上提供和雇用与施工和工程维护有关的:
(a) only such technical assistants as are skilled and experienced in their respective callings and such sub-agents,foremen and leading hands as are competent to give proper supervision to the work they are required to supervise,and
(1)对本专业熟悉和经验丰富的技术人员,能胜任规定监管工作的分代理人、工头和领班,以及
(b)such skilled,semi-skilled and unskilled labor as is necessary for the proper and timely execution and maintenance of the works.
(2)为正常和及时施工和维护工程所需的熟练、半熟练和非熟练工人。
(2)the engineer shall be at liberty to object to and require the contractor to remove forthwith from the works any person employed by the contractor in or about the execution ormaintenance of the works who,in the opinion of the engineer,misconducts himself,or is incompetent or negligent in the proper performance of his duties,or whose employment is otherwise considered by the engineer to be undesirable and such person shall not be again employed upon the works without the written permission of the engineer.any person so removed from the works shall be replaced as soon as possible by a competent substitute approved by the engineer.
16.2如工程师认为承包人雇来进行或有关施工或工程维护的任何人员行为不轨、或不能或疏于履行其职责、或认为其雇佣纯属不必要,工程师有权反对雇佣,并要求承包人立即将其从工地解雇,未经工程师的书面同意,此种人员不得再被雇用到工地。凡被从工地解雇人员的职位应尽快由工程师认可的称职人选接替。
17.the contractor shall be responsible for the true and proper setting-out of the works in relation to original points,lines and levels of reference given by the engineer in writing and for the correctness,subject as above mentioned,of the position,levels,dimensions and alignment of all parts of the works and for the provision of all necessary instruments,appliances and labor in connection therewith.if,at any time during the progress of the works,any error shall appear or arise in the position,levels,dimensions or alignment of any part of the works,the contractor, on being required so to do by the engineer or the engineer's representative,shall,at his own cost,rectify such error to the satisfaction of the engineer or the engineer's representative,unless such error is based on incorrect data supplied in writing by the engineer or the engineer's representative,in which case the expense of rectifying the same shall be borne by the employer. the checking of any setting-out or of any line or level by the engineer or the engineer's representative shall not in any way relieve the contractor of his responsibility for the correctness thereof and the contractor shall carefully protect and preserve all bench-marks, sight-rails,pegs and other things used in setting-out the works.
17.承包人负责按工程师提交的书面参考原图的有关点、线和面的规定,忠实恰当地进行测定放线,如上所述,使工程的位置、水平、面积正确无误,并校准工程的各部分,且负责提供与工程相关的所有必要工具、设备和劳力。在施工中,如任何时候在工程的位置、水平、面积或工程任何部分的校正出现差错,应工程师或工程师代表的要求,承包人必须改正错误以使工程师或工程师代表满意,改正费用由承包人自己承担,此种错误是由工程师或工程师代表提供的书面资料差错而导致的除外,在这种情况下,须由业主承担改正费用。承包人不得因工程师或工程师代表对任何位置测定或任何线或任何水平面的检查而免去确保其正确无误的责任,承包人必须仔细保护和保存工程位置测定中使用过的水准点、观测杆、测标及其他物品。
18.if,at any time during the execution of the works,the engineer shall require the contractor to make bore holes or to carry out exploratory excavation,such requirement shall be ordered in writing and shall be deemed to be an addition ordered under the provisions of clause 51 hereof,unless a provisional sum in respect of such anticipated work shall have been included in the bill of quantities.
18.在施工中,工程师如在任何时间要求承包人钻孔或进行挖掘勘探,此种要求必须作成书面形式,且得视为是根据本合同第51条规定作出的附加命令,除非数量清单中已经列有有关此种预计工程的备用款。
19.the contractor shall in connection with the works provide and maintain at his own cost all lights,guards,fencing and watching when and where necessary or required by the engineer or the engineer's representative,or by any duly constituted authority, for the protection of the works,or for the safety and convenience of the public or others.
19.凡有必要或应工程师或工程师代表、或任何正式成立的工程管理处的要求,承包人必须自费提供和维护与工程有关的所有灯光、警卫、栅栏和看护以保卫工程,或保障公众及其他人的安全和便利。
20.(1)from the commencement of the works until the date stated in the certificate of completion for the whole of the works pursuant to clause 48 hereof the contractor shall take full responsibility for the care thereof.provided that if the engineer shall issue a certificate of completion in respect of any part of the permanent works the contractor shall cease to be liable for the care of that part of the permanent works from the date stated in the certificate of completion in respect of that part and the responsibility for the care of that part shall pass to the employer. provided further that the contractor shall take full responsibility for the care of any outstanding work which he shall have undertaken to finish during the period of maintenance until such outstanding work is completed.in case any damage,loss or injury shall happen to the works,or to any part thereof,from any cause whatsoever,save and except the excepted risks as defined in subclause(2)of this clause,while the contractor shall be responsible for the care thereof the contractor shall,at his own cost,repair and make good the same,so that at completion the permanent works shall be in good order and condition and in conformity in every respect with the requirements of the contract and the engineer's instructions.in the event of any such damage loss or injury happening from any of the excepted risks,the contractor shall,if and to the extent required by the engineer and subject always to the provisions of clause 65 hereof, repair and make good the same as aforesaid at the cost of the employer.the contractor shall also be liable for any damage to the works occasioned by him in the course of any operations carried out by him for the purpose of completing any outstanding work or complying with his obligations under clauses 49 or 50 hereof.
20.1从开工至按本合同第48条中的竣工证书规定的日期为止,承包人都得对工程全权负责。只要工程师就永久性工程的任何部分签发了竣工证书,承包人从部分竣工证书中规定的日期起不再对永久性工程的此部分负责,此部分的责任则转至业主。此外,承包人必须对任何尚未完工而他得在维护期内完成的工程负全权维护,直至此种工程完工。如工程或其任何部分出现任何损害、损失或毁坏,不论何种原因,除本条第2款规定的除外风险外,承包人均得自费负责修理和修补,以确保永久性工程竣工时处于状态良好,各方面都合乎合同的要求和工程师的指示。如因除外风险而导致任何损害、损失或毁坏发生,承包人必须应工程师的要求(如果有)以及本合同第65条的规定,如上所述,进行修理和修补,费用由业主承担。承包人也必须对为完成未竣工程或履行本合同第49或50条规定的义务,在施工过程中对工程造成的任何损害负责。
(2)“the excepted risks' are war,hostilities(whether war be declared or not),invasion act of foreign enemies,rebellion,revolution,insurrection or military or usurped power,civil war,or unless solely restricted to employees of the contractor or of his sub-contractors and arisingfrom the conduct of the works,riot,commotion or disorder,or use or occupation by the employer of any part of the permanent works,or a cause solely due to the engineer's design of the works,or ionizing radiation,or contamination by radio-activity from any nuclear fuel or from any nuclear waste from the combustion of nuclear fuel,radio-active toxic explosive,or other hazardous properties of any explosive,nuclear assembly or nuclear component thereof,pressure waves caused by aircraft or other aerial devices travelling at sonic or supersonic speeds,or any such operation of the forces of nature as an experienced contractor could not foresee,or reasonably -make provision for or insure against all of which are herein collectively referred to as“the excepted risks'.
20.2“除外风险”包括战争、敌对状态(无论是否宣战)、侵略、外国敌人行为、叛乱、革命、起义或兵变或篡权、内战、或不是由承包商的雇员、其转包人单独制造和不是因工程管理而发生的暴动、骚乱或混乱、或因业主使用或占用任何部分的永久性工程、或纯属工程师工程设计的原因、或因任何核燃料或核燃料燃烧后的废料以及放射性有毒爆炸物引起的辐射和污染、或任何爆炸物、核装置或核装置部件的其他危险特性、以音速、超音速飞行的飞机或其他飞行物的压力波以及其他任何此种自然力的作用,其不能为有经验的承包商所预见,也不能合理提供物资或投保与之对抗,所有这一切在本合同中都被称为“除外风险”。
21.without limiting his obligations and responsibilities under clause 20 hereof,the contractor shall insure in the joint names of the employer and the contractor against all loss or damage from whatever cause arising,other than the excepted risks,for which he is responsible under the terms of the contract and in such manner that the employer and contractor are covered for the period stipulated in clause 20(1)hereof and are also covered during the period of maintenance for loss or damage arising from a cause,occurring prior to the commencement of the period of maintenance,and for any loss or damage occasioned by the contractor in the course of any operations carried out by him for the purpose of complying with his obligations under clauses 49 and 50 hereof;
21.承包人必须以业主和承包人的共同名义,为防止合同规定的应由承包人负责的、除外风险外的一切损失或损害投保,不论其由什么原因造成,此种投保不得减少本合同第20条所规定的承包人的义务和责任,业主和承包人的保险除包括本合同第20.1条规定的期限外,还包括因维护期开始前发生的原因而在维护期内产生的损失或损害,以及承包人在履行本合同第49或50条规定的义务而开展任何工作期间所造成的任何损失或损害。投保项目包括:
(a)the works for the time being executed to the estimated current contract value thereof,or such additional sum as may be specified in part 11 in the clause numbered 21,together with the materials for incorporation in the works at their replacement value.
(1)正在施工的工程,按其目前的合同价值,或按21条第2款可能规定的附加款额,连同按替换价值计算的用于工程的材料。
(b)the constructional plant and other things brought on to thethe replacement value of such constructional plant and other things.
(2)承包商带到工地上的建筑成套设备和其他物品,按其替换价值投保。
such insurance shall be effected with an insurer and in terms apwhich approval shall not be unreasonably withheld, and the contractor shall , whenever required , produce to the engineer or the engineer's representative the policy or policies of insurance and the receipts for payment of the current premiums.
此种保险必须在一保险公司投放,条款得经业主认可,业主不得无故不同意投保,承包人必须随时应要求向工程师或工程师代表出示保险单和支付现行保险费的收据。
22.(1)the contractor shall,except if and so far as the contract provides otherwise,indemnify the employer against all losses and claims in respect of injuries or damage to any person or material or physical damage to any property whatsoever which may arise out of or in consequence of the execution and maintenance of the works and against all claims,proceedings,damages,costs,charges and expenses whatsoever in respect of or in relation thereto except any compensation or damages for or with respect to:
22.1除合同另有规定外,承包人必须保护业主不得因施工和工程维护而产生或导致的任何人员伤害、材料损失及财产损失而受任何损失和作任何赔偿,且不因所有与之有关的任何索赔、 诉讼 、损害 赔偿金 、 诉讼费 、开支和费用而受损失,对下列事项所作或与之有关的补偿或损害赔偿除外:
(a)the permanent use or occupation of land by the works or any part thereof.
工程或部分工程永久使用或占用土地;
(b)the right of the employer to execute the works or any part thereof on,over,under in or through any land.
业主在任何土地面上、上方、下面、里面或经过部分施工或部分施工的权利;
(c)injuries or damage to persons or property which are the unavoidable result of the execution or maintenance of the works in accordance with the contract.
按合同规定施工或维护工程而不可避免的人身伤害或财产损失;
(d)injuries or damage to persons or property resulting from any act or neglect of the employer,his agents,servants or other contractors,not being employed by the contractor,or for or in respect of any claims,proceedings,damages,costs,charges and expenses in respect thereof or in relation thereto or where the injury or damage was contributed to by the contractor, his servants or agents such part of the compensation as may be just and equitable having regard to the extent of the responsibility of the employer,his servants or agents or other contractors for the damage or injury.
因业主、其代理人、雇员或其他不为承包人所雇用的承包商的任何行为或过失所造成的人员伤害或财产损失,或与之有关的任何索赔、诉讼、损害赔偿金、诉讼费、开支和费用,或曾由承包人、其雇员或代理人承担的,但原本应当由业主、其雇员或代理人或其他承包商负责的那部分涉及损失或伤害的赔偿。
(2)the employer shall indemnify the contractor against all claims,proceedings,damages,costs, charges and expenses in respect of the matters referred to in the provision sub-clause (1)of this clause.
22.2业主必须保护承包人不因与本条第1款规定事项有关的一切索赔、诉讼、损害赔偿金、诉讼费、开支和费用而受损失。
23.(1)before commencing the execution of the works the contractor,but without limiting
his obligations and responsibilities under clause 22 hereof,shall insure against his liability for anymaterial or physical damage,loss or injury which may occur to any property,including that of the employer,or to any person,including any employee of the employer,by or arising out of the
execution of the works or in the carrying out of the contract,otherwise than due to the matters referred to in the provision clause 22(1)hereof.
23.1在开工前,在不减少本合同第22条规定给他的义务和责任条件下,承包人必须对任何可能由于或因施工或因履行本合同而给包括业主的财产在内的任何财产,以及给包括业主的雇员在内的任何人员造成的重大或实质性损害、损失或伤害进行责任保险,本合同第22条规定的事项除外。
(2)such insurance shall be effected with an insurer and in terms approved by the employer,which approval shall not be unreasonably withheld,and for at least the amount stated in the appendix to the tender.the contractor shall,whenever required,produce to the engineer or the engineer's representative the policy or policies of insurance and the receipts for payment of
the current premiums.
23.2此种保险必须在一保险公司投放,条款得经业主认可,业主不得无故不同意投保,保险金额不得少于标书附件规定的数额。承包人必须随时应要求向工程师或工程师代表出示保险单和支付现行保险费的收据。
(3)the terms shall include a provision whereby,in the event of any claim in respect of which the contractor would be entitled to receive indemnity under the policy being brought or made against the employer,the insurer will indemnify the employer against such claims and any costs,charges and expenses in respect thereof.
23.3保险条款中必须规定,承包人不得对可能得到保险赔偿的有关事项对业主提出任何索赔,保险公司应保护业主免受索赔损失,且赔偿其有关的任何诉讼费及开支和费用。
24.(1)the employer shall not be liable for or in respect of any damages or compensation payable at law in respect or in consequence of any accident or injury to any workman or other person in the employment of the contractor or any sub-contractor,save and except an accident or injury resulting from any act or default of the employer,his agents,or servants. the contractor shall indemnify and keep indemnified the employer against all such damages and compensation, save and except as aforesaid,and against all claims,proceedings,costs,charges and expenses whatsoever in respect thereof or in relation thereto.
24.1业主不对因承包人或任何转包人的工人或其他雇用人员的任何事故或伤害而根据法律应予支付的任何赔偿金负责,除非事故或伤害是由业主、其代理人或雇员的任何行为或玩忽职守引起的。除上述规定外,承包人得保护业主不因所有此种损害赔偿,以及因与此有关的所有索赔、诉讼、诉讼费、开支和费用而受损失。
(2)the contractor shall insure against such liability with an insurer approved by the employer,which approval shall not be unreasonably withheld,and shall continue such insurance
during the whole of the time that any persons are employed by him on the works and shall,when
required,produce to the engineer or the engineer's representative such policy of insurance and the receipt for payment of the current premium.provided always that,in respect of any persons employed by any sub-contractor,the contractor's obligation to insure as aforesaid under this sub-
clause shall be satisfied if the sub-contractor shall have insured against the liability in respect ofsuch persons in such manner that the employer is indemnified under the policy,but the contractor shall require such sub-contractor to produce to the engineer or the engineer's representative,when required,such policy of insurance and the receipt for the payment of the current premium.
24.2承包人必须就此种责任投保,保险公司得经业主同意,业主不得无故不予同意,承包人必须在工地雇用工人的整个期间继续保险,并随时应要求向工程师或工程师代表出示此种保险单和支付现行保险费的收据。就任何转包人所雇用的人员,如转包人已经就此种人员的责任投保,且以业主为保险补偿对象,则承包人上述的投保义务得被视作已经履行,但承包人必须要求此转包人随时应要求向工程师或工程师代表出示此种保险单和支付现行保险费的收据。
25.if the contractor shall fail to effect and keep in force the insurance referred to in clauses
21,23 and 24 hereof,or any other insurance which he may be required to effect under the terms of the contract,then and in any such case the employer may effect and keep in force any such insurance and pay such premium or premiums as may be necessary for that purpose and from time to time deduct the amount so paid by the employer as aforesaid from any monies due or which may become due to the contractor,or recover the same as a debt due from the contractor.
25.如果承包人未按本合同第21、23和24条的规定投保和继续保险,或未按本合同条款规定就应由他投的其他任何保险进行投保,在任何此种情况下,业主可购买和继续任何保险,支付此种必要的费用,且随时从应付或可能应付给承包人的款项中将业主上述所支付的费用扣除,或将此作为承包人的负债追偿。
26.(1)the contractor shall give all notices and pay all fees required to be given or paid by any national or state statute,ordinance,or other law,or any regulation,or by-law of any local or other duly constituted authority in relation to the execution of the works and by the rules and regulations of all public bodies and companies whose property or rights are affected or may be affected in any way by the works.
26.1承包人必须按国家或州一切有关施工的制定法、法令、或其他 法规 、或任何条例、或当地或其他合法当局的地方法规以及所有其财产或权利受到或可能受到工程影响的公共团体和公司的规章制度的规定,发布所有的通告和支付所有的费用。
(2) the contractor shall conform in all respects with the provisions of any such statute,ordinance or law as aforesaid and the regulations or by-laws of any local or other duly constituted authority which may be applicable to the works and with such rules and regulations of public bodies and companies as aforesaid and shall keep the employer indemnified against all penalties and liability of every kind for breach of any such statute,ordinance or law,regulation or by-law.
26.2承包人必须遵守以上任何制定法、法令或法规,可适用于工程的当地或其他合法当局的一切地方法规,以及上述公共团体和公司的规章制度,如违反上述任何此种制定法、法令或法规、条例或地方法规,不得让业主受任何惩罚和承担任何责任。
(3)the employer will repay or allow to the contractor all such sums as the engineer shall certify to have been properly payable and paid by the contractor in respect of such fees.
26.3如工程师证实业主应偿还已由承包人支付的此种费用,业主应偿付或同意偿付承包人所有此种金额。
27.all fossils,coins,articles of value or antiquity and structures and other remains or things of geological or archaeological interest discovered.the works shall as between the employer and the contractor be deemed to be the absolute property of the employer.the contractor shall take reasonable precautions to prevent his workmen or any other persons from removing or damaging any such article or thing and shall immediately upon discovery thereof and,befor lemoval,acquaint the engineer's representative of such discovery and carry out,at the expense of the employer,the engineer's representative's orders as to the disposal of the same.
27.所有在工地发现的化石、钱币、有价值的物品或古物、建筑物和其他具有地质或考古价值的遗址或物品,均应被业主和承包人共同认定为是业主的绝对财产。承包人必须采取恰当的措施,防止其工人或其他任何人转移或破坏任何此种物品,并在物品发现后不得转移,立即通知工程师代表并执行工程师代表的有关处置命令,其费用由业主承担。
28.the contractor shall save harmless and indemnify the employer from and against all claims and proceedings for or on account of infringement of any patent rights,design,trademark or name or other protected rights in respect of any constructional plant,machine work,or material used for or in connection with the works or any of them and from and against all claims, proceedings,damages,costs,charges and expenses whatsoever in respect thereof or in relation thereto. except where otherwise specified,the contractor shall pay all tonnage and other royalties,rent and other payments or compensation,if any,for getting stone,sand,gravel clay or other materials required for the works or any of them.
28.承包人必须保护业主不得因在工程或部分工程中使用或涉及到任何建筑设备、机械加工、或材料,从而侵犯与之有关的 专利权 、外观设计、 商标 或商号或其他应受保障的权利而遭索赔或被起诉,并必须保护业主免受与此有关的任何索赔、诉讼、损害赔偿金、诉讼费、支出或费用的损害。除另有规定外,承包人必须承担工程或部分工程所需的石头、沙子、砂砾、泥土或其他材料的运费、沙石产地使用费、租金和其他费用或补偿(如果有)。
29.all operations necessary for the execution of the works shall,so far as compliance with the requirements of the contract permits,be carried on so as not to interfere unnecessarily or improperly with the convenience of the public,or the access to,use and occupation of public or private roads and footpaths to or of properties whether in the possession of the employer or of any other person.the contractor shall save harmless and indemnify the employer in respect of all claims, proceedings,damages,costs,charges and expenses whatsoever arising out of,or in relation to,any such matters in so far as the contractor is responsible therefor.
29.所有施工必需的活动,凡符合合同许可证的规定,必须开展,从而保证不无故妨碍公众的便利,或妨碍公共或私人道路的通行、使用和占用,无论道路是通向或是在业主或其他人的地产上。倘若发生此类应由承包人负责的事件,承包人必须保护业主免受由此而引而起的任何索赔、诉讼、损害赔偿费、诉讼费、开支和费用的损害。
30.(1)the contractor shall use every reasonable means to prevent any of the highways or bridges communicating with or on the routes to the site from being damaged or injured by any traffic of the contractor or any of his sub一contractors and,in particular,shall select routes, choose and use vehicles and restrict and distribute loads so that any such extraordinary traffic as will inevitably arise from the moving of plant and material from and to the site shall be limited asfar as reasonably possible,and so that no unnecessary damage or injury may be occasioned to such highways and bridges.
30.1承包人必须采取各种合理手段,防止连接或通向工地的任何公路或桥梁由于承包人或其任何转包人的使用而遭受损害,承包人尤其必须挑选路线、选择使用车辆,限制和分散装载量,从而使因往来于工地的设备和材料的运输而必然造成的异常交通尽可能地被合理限
制,由此避免对公路和桥梁造成不必要的损害。
(2)should it be found necessary for the contractor to move one or more loads of constructional plant,machinery or pre一constructed units or parts of units of work over part of a highway or bridge,the moving whereof is likely to damage any highway or bridge unless special protection or strengthening is carried out,then the contractor shall before moving the load on to such highway or bridge give notice to the engineer or engineer's representative of the weight and other particulars of the load to be moved and his proposals for protecting or strengthening the said highway or bridge.unless within fourteen days of the receipt of such notice the engineer shall by counternotice direct that such protection or strengthening is unnecessary,then the contractor will carry out such proposals or any modification thereof that the engineer shall require and,unless there is an item or are items in the bill of quantities for pricing by the contractor of the necessary works for the protection or strengthening aforesaid,the costs thereof shall be paid by the employer to the contractor.
30.2如承包人必须经部分公路或桥梁一次或多次运送建筑设备、机械或工程预制件或预制部件,如不采取特殊保护和加固措施,此种运送很可能损坏公路或桥梁,承包人运送货物通过此公路或桥梁前必须通知工程师或工程师代表,告之运送货物的重量及其他具体情况,以及其拟对上述公路或桥梁采取的保护和加固措施。除非在接到通知14天内,工程师以取消通知的方式指示不必采取此种保护或加固措施,承包人将施行此种方案或施行经工程师要求修改后的方案,除非建筑工程清单中含有一项或多项已由承包人标价的上述公路或桥梁保护或加固的必要项目,其费用得由业主向承包人支付。
(3) if during the execution of the works or at any time thereafter the contractor shall receive any claim arising out of the execution of the works in respect of damage or injury to highways or bridges he shall immediately report the sums to the engineer and thereafter the employer shall negotiate the settlement of and pay all sums due in respect of such claim and shall indemnify the contractor in respect thereof and in respect of all claims,proceedings,damages,costs,charges and expenses in relation thereto. provided always that if and二far as any such claims or part thereof shall in the opinion of the engineer be due to any failure on the part of the contractor to observe and perform his obligations under sub-clauses(1) and(2)of this clause,then the amount certified by the engineer to be due to such failure shall be paid by the contractor to the employer.
30.3如果在施工期间或以后任何时间,承包人因施工损坏公路或桥梁而被索赔,他必须立即报告工程师,其后,业主将商洽解决并支付索赔款,并保护承包人免受该索赔以及与之有关的一切索赔、诉讼、损害赔偿金、诉讼费、开支和费用的损害。如果工程师认为造成此种索赔或部分索赔的原因在于承包人没有履行本条第1款和第2款规定的义务,由工程师确认的因此种不履行而损失的款额必须由承包人支付给业主。
(4)where the nature of the works is such as to require the use by the contractor ofwaterborne transport the foregoing provisions of this clause shall be construed as though “highway' included a lock,dock,sea wall or other structure related to a waterway and“vehicle' included craft,and shall have effect accordingly.
30.4如果工程性质需要承包人使用水路运输,本条上述规定必须按“公路”包括船闸、码头、防波堤或其他有关的水路设施,“运输工具”包括船只来予以解释,并由此而施行。
31.the contractor shall,in accordance with the requirements of the engineer,afford all reasonable opportunities for carrying out their work to any other contractors employed by the employer and their workmen and to the workmen of the employer and of any other duly constituted authorities who may be employed in the execution on or near the site of any work not included in the contract or of any contract which the employer may enter into in connection with or auxiliary to the works.if,however,the contractor shall,on the written request of the engineer or the engineer's representative,make available to any such other contractor,or to the employer or any such authority,any roads or ways for the maintenance of which the contractor is responsible,or permit the use by any such of the contractor's scaffolding or other plant on the site,or provide any other service of whatsoever nature for any such,the employer shall pay to the contractor in respect of such use or service such sum or sums as shall,in the opinion of the engineer,be reasonable,
31.承包人必须按工程师的要求,为业主雇用的其他承包商及其工人,以及为业主或其他合法当局雇用的工人提供合理开展工作的机会,这些工人可受雇在工地上或附近,从事不为本合同规定的任何工作或由业主签订的与工程有关或附属工程的任何其他合同规定的工作。然而,如承包人应工程师或工程师代表的书面要求,为其他承包人、业主或其他合法当局提供由他负责维护的道路,或准许使用其在工地的脚手架或其他设备,或提供其他任何类似性质的服务,业主必须向承包人支付有关此种使用或服务的费用,只要工程师认为合理。
32.during the progress of the works the contractor shall keep the site reasonably free from all unnecessary obstruction and shall store or dispose of any constructional plant and surplus materials and clear away and remove from the site any wreckage,rubbish or temporary works no longer required.
32.在施工期间,承包人应保证工地没有任何不必要的障碍物,妥善储存或处置建筑设备和多余的材料,将所有残余物垃圾或不再需要的临时工程设施清理出工地。
33.on the completion of the works the contractor shall clear away and remove from the site all constructional plant,surplus materials,rubbish and temporary works of every kind,and leave the whole of the site and works clean and in a workmanlike oondition to the satisfaction of the engineer.
33.完工之后,承包人应将所有建筑设备、多余材料、垃圾和各种临时工程设施清理出工地,使整个工地和工程显得整洁合乎标准,让工程师满意。
labor
劳工
34.(1)the contractor shall make his own arrangements for the engagement of all labor,local or otherwise,and save insofar as the contract otherwise provides,for the transport,housing feeding and payment thereof.
34.1承包人必须自己安排雇用所有当地或其他地方的劳工,并负责劳工的交通、食宿和 工资 ,本合同另有规定的除外。
(2)the contractor shall,so far as is reasonably practicable,having regard to local conditions,provide on thesite,to the satisfaction of the engineer's representative,an adequate supply of drinking and other water for the use of the contractor's staff and work people.
34.2只要合理可行,承包人应视当地情况,向工地的职员和工人提供充足的饮水和其他用水,让工程师代表感到满意。
(3)the contractor shall not,otherwise than in accordance with the statutes,ordinances and government regulations or orders for the time being in force,import,sell,give,barter or otherwise dispose of any alcoholic liquor,or drugs,or permit or suffer any such importation,sale,gift,barter or disposal by his sub-contractors,agents or employees.
34.3除非根据现行法律、法规及政府规章或命令,承包人不得进口、销售、赠予、以物交换或以其他方式处置任何烈酒或毒品,或允许或容忍转包人、代理人或雇员参与任何此种物品的进口、销售、赠予、交换或处置。
(4)the contractor shall not give,barter or otherwise dispose of to any person or persons,any arms or ammunition of any kind or permit or suffer the same as aforesaid.
34.4如上所述,承包人不得向他人赠予、交换或以其他方式处置任何武器或弹药,也不得准许或容忍同样行为发生。
(5)the contractor shall in all dealings with labor in his employment have due regard to allrecognized festivals,days of rest and religious or other customs.
34.5在处理与雇工的关系时,承包人应适当注意公认的节假日和宗教或其他习俗。
(6) in the event of any outbreak of illness of an epidemic nature,the contractor shall comply with and carry out such regulations,orders and requirements as may be made by the government,or the local medical or sanitary authorities for the purpose of dealing with and overcoming the same.
34.6一旦爆发传染病,承包人必须遵守并执行政府或当地医疗卫生机构为治疗此种疾病所制定的规章、命令及要求。
(7)the contractor shall at all times take all reasonable precautions to prevent any unlawful, riotous or disorderly conduct by or amongst his employees and for the preservation of peace and protection of persons and property in the neighborhood of the works against the same.
34.7承包人应随时采取一切合理的预防措施,防止其雇员制造或在雇员中发生违法、骚乱或混乱行为,以维护治安和保护工程附近地区人员和财产的安全。
(8)the contractor shall be responsible for observance by his sub-contractors of the foregoing provisions.
34.8承包人必须负责让其转包人遵守上述规定。
(9)any other conditions affecting labor and wages shall be as set out in partⅱin the clause numbered 34 as may be necessary.
34.9如有必要,可在第二部分的第34条就所有其他有关劳工和工资的条件作出规定。
35.the contractor shall,if required by the engineer,deliver to the engineer representative,or at his office,a return in detail in such form and at such intervals as theengineer may prescribe showing the supervisory staff and the numbers of the several classes of labor from time to time employed by the contractor on the site and such information respecting constructional plant as the engineer's representative may require.
35.如工程师要求,承包人应按工程师要求的格式和时间向工程师代表或其办公室提交一份详细报告,汇报其在工地随时雇用的监督人员和不同等级劳工的数量,以及工程师代表可能要求的有关建设设备的情况。
materials and worship
材料和工艺
36.(1)all materials and workmanship shall be of the respective kinds described in the contract and in accordance with the engineer's instructions and shall be subjected from time to time to such tests as the engineer may direct at the place of manufacture or fabrication,or on the site or at such other place or places as may be specified in the contract,or at all or any of such places. the contractor shall provide such assistance,instruments,machines,labor and materials as are normally required for examining,measuring and testing any work and the quality,weight or quantity of any material used and shall supply samples of materials before incorporation in the works for testing as may be selected and required by the engineer.
36.1所有材料和工艺均应符合合同的规定和工程师的指令,且应随时在制造或加工地、工地或合同具体规定的其他地点,同时或在某一处,接受工程师可能命令进行的检验。承包人要为任何工程或任何材料的质量、重量或数量的检查、测量和检验提供正常所需的帮助、工具、机械、劳力和材料,承包人还必须应工程师可能的选择和要求,在材料应用于工程之前提供材料样品以供检验。
(2)all samples shall be supplied by the contractor at his own cost if the supply thereof is
clearly intended by or provided for in the contract,but if not,then at the cost of the employer.
36.2如合同明显默示或明文规定,所有由承包人提供的样品的费用应由承包人自己承担,否则应由业主支付。
(3)the cost of making any test shall be borne by the contractor if such test is clearly intended by or provided for in the contract and,in the cases only of a test under load or of a test to ascertain whether the design of any finished or partially finished work is appropriate for the purposes which it was intended to fulfil,is particularized in the contract in sufficient detail to enable the contractor to price or allow for the same in his tender.
36.3如合同明显默示或明文规定,一切检验费用应由承包人负担,对于仅是负载检测和确认任何完成或部分完成的工程之设计是否符合要求的检验,本合同作有详尽规定,可确保或准许承包商将其费用计人投标价格中。
(4)if any test is ordered by the engineer which is either.
36.4凡是工程师命令所作的检验,而
(a)not、intended by or provided for,or
合同没有默示或规定,或
(b)(in the cases above mentioned)is not so particularized,or
(在上述情况中)没有如此详细规定,或
(c)though so intended or provided for is ordered by the engineer to be carried out by an independent person at any place other than the site or the place of manufacture or fabrication of the materials tested,
虽有默示或规定,但却是由工程师命令独立个人在工地之外,或在该检验物资的制造或加工地之外的任何地点进行的,
then the cost of such test shall be borne by the contractor,if the test shows the workmanship or materials not to be in accordance with the provisions of the contract or the engineer's instructions,but otherwise by the employer.
如检验结果表明工艺或材料不符合合同规定或工程师指令,检验费由承包人承担,否则由业主支付。
37.the engineer and any person authorized by him shall at all times have access to the works and to all workshops and places where work is being prepared or from where materials, manufactured articles or machinery are being obtained for the works and the contractor shall afford every facility for and every assistance in or in obtaining the right to such access.
37.工程师和他授权的任何人随时有权到工程现场,到任何工程准备地或工程所需材料、制品或机械获得地,承包人应为其行使或获得此种到场权利提供一切便利和帮助。
38.(1)no work shall be covered up or put out of view without the approval of the engineer or the engineer's representative and the contractor shall afford full opportunity for the engineer or the engineer's representative to examine and measure any work which is about to be covered up or put out of view and to examine foundations before permanent work is placed thereon.the contractor shall give due notice to the engineer's representative whenever any such work or foundations is or are ready or about to be ready for examination and the engineer's representative shall,without unreasonable delay,unless he considers it unnecessary and advises the contractor accordingly,attend for the purpose of examining and measuring such work or of examining suchfoundations.
38.1未经工程师或工程师代表的认可,任何工程不得被覆盖或遮掩,承包人应为工程师或工程师代表提供充分机会,以检查和测量即将被覆盖或遮掩的任何工程,以及在永久性工程开始前检查地基。承包人应在任何此种工程或地基做好或即将做好检查准备时及时通知工程师代表,工程师代表必须参加此种工程或地基的检查,不得无故拖延,除非他认为检查没有必要,且由此通知承包人。
(2)the contractor shall uncover any part or parts of the works or make openings in or through the same as the engineer may from time to time direct and shall reinstate and make good such part or parts to the satisfaction of the engineer.if any such part or parts have been covered
up or put out of view after compliance with the requirement of sub-clause(1)of this clause and
are found to be executed in accordance with the contract,the expenses of uncovering,making
openings in or through,reinstating and making good the same shall be borne by the employer,
but in any other case all costs shall be borne by the contractor.
38.2承包人必须应工程师随时作出的指示,打开业已覆盖的工程某一或某些部分,或在工程上或经过工程开通道,并负责使之完好复原而让工程师满意。凡任何此种工程部分是在履行本条第1款之规定后被覆盖或遮掩的,则打开和在工程上或经过工程开通道,以及使之完全复原的费用由业主承担,否则所有费用应由承包人承担。
39.(1)the engineer shall during the progress of the works have power to order in writing
from time to time:
39.1在施工中,工程师有权随时书面命令:
(a) the removal from the site,within such time or times as may be specified in the order,
of any materials which,in the opinion of the engineer,are not in accordance with the contract,
把工程师认为不符合合同规定的任何材料按命令中具体规定的时间从工地换走,
(b)the substitution of proper and suitable materials and,
用恰当合适的材料予以替换和
(c)the removal and proper re-execution,notwithstanding any previous test thereof or interim payment therefor,of any work which in respect of materials or workmanship is not,in the opinion of the engineer,in accordance with the contract.
把工程师认为不符合合同规定的材料或工艺换掉或适当重新施工,无论其在之前是否经过检查或作过中期支付。
(2)in case of default on the part of the contractor in carrying out such order,the employer shall be entitled to employ and pay other persons to carry out the same and all expenses consequent hereon or incidental thereto shall be recoverable from the contractor by the employer,or may be deducted by the employer from any monies due or which may become due to the contractor.
39.如承包人未执行此种命令,业主有权雇用他人执行,业主应从承包人处收回由此而产生的所有费用和杂费,或从应付给或即将付给承包商的款项中予以扣除。
40.(1)the contractor shall,on the written order of the engineer,suspend the progress of the works or any part thereof for such time or times and in such manner as the engineer may consider necessary and shall during such suspension properly protect and secure the work,so far as is necessary in the opinion of the engineer.the extra cost incurred by the contractor in giving effect to the engineer's instructions under this clause shall be borne and paid by the employer unless such suspension is:
40.1收到工程师的书面命令后,承包人必须在工程师认为必要的时间,以其认为必要的方式,停止工程或部分工程的施工,只要工程师认为必要,还必须在停工期间妥善保护工程的安全。承包人根据本条款执行工程师指令而发生的额外费用应由业主承担,除非此种停工是:
(a)otherwise provided for in the contract,or
合同另行规定的,或
(b)necessary by reason of some default on the part of the contractor,or
由承包人的某种违约而导致的必要停工,或
(c) necessary by reason of climatic conditions on the site,or
由工地的气候条件导致的必要停工,或
(d)necessary for the proper execution of the works or for the safety of the works or anypart thereof insofar as such necessity does not arise from any act or default by the engineer or the employer or from any of the excepted risks defined in clause 20 hereof.
为正常施工或为整个工程或部分工程的安全而作的必要停工,而不是因工程师或业主的任何行为或违约而产生的,也不是因本合同第20条规定的任何除外风险引起的。
provided that the contractor shall not be entitled to recover any such extra cost unless he gives written notice of his intention to claim to the engineer within days of the engineer's order.the engineer shall settle and determine such extra payment and/or extension of time under clause 44 hereof to be made to the contractor in respect of such claim as shall,in the opinion of the engineer,be fair and reasonable.
承包人在收到工程师命令后xx天内应书面通知工程师,要求赔偿,否则将无权得到额外费用。如工程师认为承包人的要求公平合理,他必须按本合同第44条的规定,处理并决定此种支付给承包人的额外费用和/或停工时间。
(2)if the progress of the works or any part thereof is suspended on the written order of the engineer and if permission to resume work is not given by the engineer within a period of ninety days from the date of suspension then,unless such suspension is within paragraph(a),(b),(c) or(d)of sub—clause(1)of this clause,the contractor may serve a written notice on the engineer requiring permission within days from the receipt thereof to proceed with the works,or that part thereof in regard to which progress is suspended and,if such permission is not granted within that time,the contractor by a further written notice so served may,but is not bound to,elect or treat the suspension where it affects part only of the works as an omission of such part under clause 51 hereof,or,where it affects the whole works,as an abandonment of the contract by the employer.
40.2如整个工程或部分工程按工程师的命令停工,且停工90天后仍未得到工程师作出的复工命令,除非此种停工属本条第1款第1、2,3或4项规定范围之内,否则承包人可书面通知工程师,要求其在收到通知后xx天内准许对整个工程,或停工的部分工程重新开工,如在此期间仍未获得开工许可,承包人可以,但不一定必须再作书面通知,按本合同第51条的规定将只影响到部分工程的停工视为是对该部分工程的省略,或,如停工影响到整个工程,视其为是业主废弃合同。
commencement time and delays
开工时间和延误
41.the contractor shall commence the works on site within the period named in the appendix to the tender after the receipt by him of a written order to this effect from the engineer and shall proceed with the same with due expedition and without delay,except as may be expressly sanctioned or ordered by the engineer,or be wholly beyond the contractor's control.
41.接到工程师的书面开工通知后,承包人应在标书附录中规定的期限内在工地施工,且必须迅速,不得延误,工程师明文同意或命令,或承包人无法控制的原因除外。
42.(1)save insofar as the contract may prescribe,the extent of portions of the site of which the contractor is to be given possession from time to time and the order in which such portions shall be made available to him and,subject to any requirement in the contract as to the order in which the works shall be executed,the employer will,with the engineer's written order to commence the works,give to the contractor possession of so much of the site as may berequired to enable the contractor to commence and proceed with the execution of the works in accordance with the program referred to in clause 14 hereof,if any,and otherwise in accordance with such reasonable proposals of the contractor as he shall,by written notice to the engineer, make and will,from time to time as the works proceed,give to the contractor possession of such further portions of the site as may be required to enable the contractor to proceed with the execution of the works with due dispatch in accordance with the said program or proposals,as the case may be,if the contractor suffers delay or incurs cost from failure on the part of the employer to give possession in accordance with the terms of this clause,the engineer shall grant an extension of time for the completion of the works and certify such sum as,in his opinion,shall be fair to cover the cost incurred,which sum shall be paid by the employer.
42.1除合同另有规定的外,就承包人应随时获得的工地的范围及授权他使用此部分工地的命令而言,业主应根据合同有关施工命令的规定,随同工程师的书面开工命令,提供承包人必要范围的工地,使其能够开始并按本合同第14条规定的方案施工,此外应根据承包人给工程师的书面通知上的合理建议(如果有),在施工期间随时向承包人提供更大范围的地,以保证承包人能按上述方案或建议迅速施工。如承包人因业主不按本条规定提供工地而误工或发生费用,工程师应准许延长工期,并由他确定一笔补偿此种费用的款项,该款项应由业主支付。
(2) the contractor shall bear all costs and charges for special or temporary way leaves required byhim in connection with acoess to the site. the contractor shall also provide at his own cost any additional accommodation outside the site required by him for the purposes of the works.
42.2承包人应承担因通往工地的所有特殊或临时道路通行权而产生的费用。承包人也得支付为施工而应他的要求在工地之外食宿而发生的一切额外费用。
43.subject to any requirement in the contract as to completion of any section of the works before completion of the whole,the whole of the works shall be completed,in accordance with the provisions of clause 48 hereof,within the time stated in the contract calculated from the last day of the period named in the appendix to the tender as that within which the works are to be commenced,or such extended time as may be allowed under clause 44 hereof.
43.除按合同规定,工程整体完工前任何部分工程必须按时完工外,根据合同第48条的规定,整个工程必须在合同规定的期限内完成,该期限应从标书附录规定的开工期的最后一天算起,或以本合同第44条的规定而准许的延期时间为准。
44.should the amount of extra or additional work of any kind or any cause of delay referred to in these conditions,or exceptional adverse climatic conditions,or other special circumstances of any kind whatsoever which may occur,other than through a default of the contractor,be such as fairly to entitle the contractor to an extension of time for the completion of the works,the engineer shall determine the amount of such extension and shall notify the employer and the contractor accordingly.provided that the engineer is not bound to take into account any extra or additional work or other special circumstances unless the contractor has within days after such work has been commenced,or such circumstances have arisen,or as soon thereafter as is practicable, submitted to the engineer's representative full and detailed particulars of any extension of time to which he may consider himself entitled in order that such submission may be investigated at the time.
44.除承包人违约外,如因额外工程或工程量的增加或由此而涉及的任何延误原因、或特别恶劣的气候、或其他可能发生的任何特殊情况而使得承包人有权要求工程延期,工程师应决定延期时间,并由此通知业主和承包人。如承包人在此种工程开工后、或此种情况一发生、或按实情在其发生后的xx天内,没有向工程师代表提交详细说明他认为有权延期的报告而让此陈述当时便得到调查,工程师可不予考虑额外工程或工程量的增加或其他特殊情况。
45.subject to any provision to the contrary contained in the contract,none of the permanent works shall,save as hereinafter provided,be carried on during the night or on sundays,if locally recognized as days of rest,or their locally recognized equivalent without the permission in writing of the engineer's representative,except when the work is unavoidable or absolutely necessary for the saving of life or property or for the safety of the works,in which case the contractor shall immediately advise the engineer's representative.provided always that the provisions of this clause shall not be applicable in the case of any work which it is customary to carry out by rotary or double shifts.
45.除合同另有相反规定外,未经工程师代表的书面允许,任何永久性工程不得在夜间或星期天进行,只要这些时间在当地被认作是假日,同时也不得在其他被当地认作是假日的时间进行,但下列情况除外:因工程而不得已或为挽救生命、财产或维护工程安全而绝对必要,在这种情况下,承包商应立即通知工程师代表。本条的规定不适用于按传统需轮班或倒班进行的工作。
46.if for any reason,which does not entitle the contractor to an extension of time,the rate of progress of the works or any section is at any time,in the opinion of the engineer,too slow to ensure completion by the prescribed time or extended time for completion,the engineer shall so notify the contractor in writing and the contractor shall thereupon take such steps as are necessary and the engineer may approve to expedite progress so as to complete the works or such section by the prescribed time or extended time.the contractor shall not be entitled to any additional payment for taking such steps.if,as a result of any notice given by the engineer under this clause,the contractor shall seek the engineer's permission to do any work at night or on sundays,if locally recognized as days of rest,or their locally recognized as days of rest,or their locally recognized equivalent,such permission shall not be unreasonably refused.
46.不论是何原因使得工程或其任何部分的进度让工程师觉得太慢,因而无法确保在规定或延长期限内完工,只要该原因不至于让承包人有权要求延期,工程师必须书面通知承包人,接到通知后承包人应采取必要的措施,工程师可同意加快进度,以便能在规定或延长期限内完工或完成某部分工程。承包人无权因采取此种措施而要求额外付款。如因工程师按本条款所作的通知的缘故,承包人需要求工程师准许在夜间或星期日,如果其在当地被当做假日,或在其他被当地当做是假日的时间工作,工程师不得无故不准许。
47.(1)if the contractor shall fail to achieve completion of the works within the time prescribed by clause 43 hereof,then the contractor shall pay to the employer the sum stated in the contract as liquidated damages for such default and not as a penalty for every day or part of a day which shall elapse between the time prescribed by clause 43 hereof and the date of certified completion of the works.the employer may,without prejudice to any other method of recovery,deduct the amount of such damages from any monies in his hands,due or which may become due to the contractor.the payment or deduction of such damages shall not relieve thecontractor from his obligation to complete the works,or from any other of his obligations and liabilities under the contract.
47.1如承包人未在本合同第43条规定的期限内完成工程,承包人应因违约而向业主支付合同所规定之款额,此款额为定额赔偿金,而不是根据第43条规定的期限与实际完工时间之差按天数进行处罚。业主可在不损害其他收款措施的情况下,从他手中掌握的应支付或将支付给承包人的款项中扣除此种赔偿金。此种赔偿金的支付或扣除不得免除承包人完成工程的义务,或免除他的其他任何合同所规定的责任和义务。
(2)if,before the completion of the whole of the works any part or section of the works has been certified by the engineer as completed,pursuant to clause 48 hereof,and occupied or used by the employer,the liquidated damages for delay shall,for any period of delay after such certificate and in the absence of alternative provisions in the contract be reduced in the proportion which the value of the part or section so certified bears to the value of the whole of the works.
47.2在工程全部完工前,如有某部分工程已由工程师按本合同第48条确认为完工,且已被业主占用,如在此后出现任何延误,而本合同又无另行规定,因延误本应处罚的定额赔偿金则应按已完工的工程的价值所占全部工程价值的比例予以扣减。
(3)if it is desired to provide in the contract for the payment of a bonus in relation to completion of the works or of any part or section thereof this shall be set out in part ii in the clause numbered.
47.3如要在合同中规定有关工程全部或部分完工的奖励支付事项,此规定应列在第二部分的第47条中。
48.(1)when the whole of the works have been substantially completed and have satisfactorily passed any final test that may be prescribed by the contract,the contractor may give a notice to that effect to the engineer or to the engineer's representative accompanied by an undertaking to finish any outstanding work during the period of maintenance.such notice and undertaking shall be in writing and shall be deemed to be a request by the works.the engineer shall,within _______days of the date of delivery of such notice either issue to the contractor,with
a copy to the employer,a certificate of completion stating the date on which,in his opinion,the
works were substantially completed in accordance‘with the contract or give instructions in writing to the contractor specifying all the work which,in the engineer's opinion,requires to be done by the contractor before the issue of such certificate.the engineer shall also notify the contractor of any defects in the works affecting substantial completion that may appear after sucb instructions and before completion of the works specified therein.the contractor shall be entitled to receive such certificate of completion within _______ days of completion to the satisfaction of the engineer of the works so specified and making good any defects so notified,
48.1当工程全部完工且满意地通过了所有合同规定的最后检验后,承包人可向工程师或工程师代表发出有关通知,并承诺在维修期内将完成任何未完成的工作。此种通知和承诺必须作成书面形式,且应被视作是承包人要工程师发放工程竣工证书的要求。工程师应在此种通知送出后_______天内或向承包人发出工程竣工证书,并交业主一本副本,注明他认为工程已按合同规定圆满完工的日期,或向承包人发出书面指示,具体说明他认为在发放此种证书前承包人还需完成的一切工作。在发出此种指示后,工程师还应通知承包人关于此后以及在指示中所提及之工程完工前,可能出现且会影响工程实际完工的任何欠缺。在令工程师满意地完成所指明的工程并修正一切所指明的欠缺后,承包人有权在_______天之内收到竣工证书。
(2)similarly,in accordance with the procedure set out in sub-clause(1)of this clause,the contractor may request and the engineer shall issue a certificate of completion in respect of:
48.2同样,根据本条第1款规定的程序,就以下情况,承包人可要求,且工程师应颁发竣工证书:
(a)any section of the permanent works in respect of which a separate time for completion is provided in the contract and
合同中单独作有完工期限规定的部分永久性工程竣工,以及
(b)any substantial part of the permanent works which has been both completed to the satisfaction of the engineer and occupied or used by the employer.
永久性工程的任何实体部分已竣工,令工程师满意,且已被业主占有或使用。
(3)if any part of the permanent works shall have been substantially completed and shall have satisfactorily passed any final test that may be prescribed by the contract,the engineer may issue a certificate of completion in respect of that part of the permanent works before completion of the whole of the works and,upon the issue of such certificate,the contractor shall be deemed to have undertaken to complete any outstanding work in that part of the works during the period of maintenance.
48.3如部分永久性工程已实质性完工,且满意地通过了合同规定的最后检验,工程师可在全部工程竣工前颁发此部分工程的竣工证书,一旦颁发此种证书,承包人应被视作已承诺在维修期内完成此部分工程中一切尚未完成的工作。
(4)provided always that a certificate of completion given in respect of any section or part of the permanent works before completion of the whole shall not be deemed to certify completion of any ground or surfaces requiring reinstatement,unless such certificate shall expressly so state.
48.4在工程全部完工前就永久性工程的某一部分发放竣工证书,并不视为已经完成任何所需的地面或地表还原工作,证书中明文规定的除外。
maintenance and defects
维修及欠缺
49.(1)in these conditions the expression 'period of maintenance' shall mean the period of maintenance named in the appendix to the tender,calculated from the date of completion of the works,certified by the engineer in accordance with clause 48 hereof,in the event of more than one certificate having been issued by the engineer under the said clause,from the respective dates so certified and in relation to the period of maintenance the expression“the works”shall be construed accordingly.
49.1本条款中“维修期”一词指标书附录所指的维修期,从工程师按本合同第48条规定确认的竣工日开始计算,如工程师根据上述条款发出了多份竣工证书,则分别从其确认的完工日开始计算,就维修期而言,“工程”一词须作相应解释。
(2)to the intent that the works shall at or as soon as practicable after the expiration of theperiod of maintenance be delivered to the employer in the condition required by the contract,fair wear and tear excepted,to the satisfaction of the engineer,the contractor shall finish the work, if any,outstanding at the date of completion,as certified under clause 48 hereof,as soon as practicable after such date and shall execute all such work of repair,amendment,reconstruction, rectification and making good defects,imperfections,shrinkage or other faults as may be required of the contractor in writing by the engineer during the period of maintenance,or within days after its expiration,as a result of an inspection made by or on behalf of the engineer prior to its expiration.
49.2为按合同规定条件在维修期满时或其后尽快将工程交给业主,除合理损耗外,为让工程师感到满意,承包人必须尽快完成本合同第48条中规定的在完工日尚未完成的工作(如果有),以及完成工程师在维护期间,或在维护期满后xx天内,因工程师或工程师代表在维护期满前的检查而可能书面要求承包人完成的诸如修理、修正、再建、调整,以及修正欠缺、缺陷和其他毛病等一切工作。
(3)all such work shall be carried out by the contractor at his own expense if the necessity
thereof shall,in the opinion of the engineer,be due to the use of materials or workmanship not in
accordance with the contract,or to neglect or failure on the part of the contractor to comply with
any obligation,expressed or implied,on the contractor's part under the contract.if,in the
opinion of the engineer,such necessity shall be due to any other cause,the value of such work
shall be ascertained and paid for as if it were additional work.
49.3如工程师认为此种工作是因承包人使用的材料或工艺不符合合同的要求所致,或因承包人未履行其合同义务(明示或默示不论)所致,一切费用应由承包人承担。如工程师认为此种需要是其他原因所致,则应对此种工作进行估价,并按附加工程支付。
(4)if the contractor shall fail to do any such work as aforesaid required by the engineer,the employer shall be entitled to employ and pay other persons to carry out the same and if such work is work which,in the opinion of the engineer,the contractor was liable to do at his own expense under the contract,then all expenses consequent thereon or incidental thereto shall be recoverable from the contractor by the employer,or may be deducted by the employer from any monies due or which may become due to the contractor.
49.4如承包人未完成工程师要求的上述此种工作,业主有权雇用他人完成,如工程师认为,按合同规定此工作本应由承包人自费完成,业主应向承包人追偿由此发生的一切直接或间接费用,或从应付或可能应付给承包人的任何款项中予以扣除。
50.the contractor shall,if required by the engineer in writing,search under the directions of the engineer for the cause of any defect,imperfection or fault appearing during the progress of the works or in the period of maintenance.unless such defect,imperfection or fault shall be one for which the contractor is liable under the contract,the cost of the work carried out by the contractor in searching as aforesaid shall be borne by the employer. if such defect,imperfection or fault shall be one for which the contractor is liable as aforesaid,the cost of the work carried out in searching as aforesaid shall be borne by the contractor and he shall in such case repair,rectify and make good such defect,imperfection or fault at his own expense in accordance with tkv provisions of clause 49 hereof.
50.应工程师的书面要求,承包人应根据工程师的指令,对施工过程或维修期内出现的任何欠缺、不足或缺陷进行检查。除非根据合同,此种欠缺、不足或缺陷应由承包人负责,否则上述检查工作的费用由业主承担。如此种欠缺、不足或缺陷如上所述属于承包人的责任,上述检查费用应由承包人负担,且他应按本合同第49条的规定,自费对其进行修理、修正和补救。
alterations,additions and omissions
变更、增加和省略
51.(1)the engineer shall make any variation of the form,quality or quantity of the works or any part thereof that may,in his opinion,be necessary and for that purpose,or if for any other reason it shall,in his opinion be desirable,he shall have power to order the contractor to do and the contractor shall do any of the following:
51.1如工程师认为必要,他应对整个工程或任何部分的形式、质量或工作量作相应变更,且他有权因其他任何理由,命令承包人作出且承包人必须作出以下变更:
(a) increase or decrease the quantity of any work included in the contract,
增减合同所规定的工程量,
(b)omit any such work,
省略任何部分工程,
(c) change the character or quality or kind of any such work,
改变任何部分工程的特性或质量或类别,
(d)change the levels,lines,position and dimensions of any part of the works,and
改变任何部分工程的平面、型线、位置和面积,
(e)execute additional work of any kind necessary for the completion of the works
增加竣工所需的任何额外工程,
and no such variation shall in any way vitiate or invalidate the contract,but the value,if any,of all such variations shall be taken into account in ascertaining the amount of the contract price.
但此种变更不得以任何方式使合同失效,此种变更所需的一切费用(如果有)应在确定合同价格时予以考虑。
(2)no such variations shall be made by the contractor without an order in writing of the engineer.provided that no order in writing shall be required for increase or decrease in the quantity of any work where such increase or decrease is not the result of an order given under this clause,but is the result of the quantities exceeding or being less than those stated in the bill of quantities.provided also that if for any reason the engineer shall consider it desirable to give any such order verbally,the contractor shall comply with such order and any confirmation in writing of such verbal order given by the engineer,whether before or after the carrying out of the order, shall be deemed to be an order in writing within the meaning of this clause.provided further that if the contractor shall within _______ days confirm in writing to the engineer and such confirmation shall not be contradicted in writing within _______ days by the engineer,it shall be deemed to be an order in writing by the engineer.
51.2如无工程师的书面命令,承包人不得作任何此种变更。然而,如工程量的增减不属本条规定的应作命令的范畴,而是因超过或不足建筑工程清单的规定所至,则不要求有书面命令。另外,如工程师因任何原因认为有必要口头作此种命令,承包人必须服从,且工程师对该口头命令的确认书,不论在命令执行前或后给予,都应被视作是本条款所指的书面命令。此外,如承包人在_______天内书面向工程师要求确认,而工程师在_______天内未用书面驳回此确认,其应被视为是工程师所作的书面命令。
52.(1)all extra or additional work done or work omitted by order of the engineer shall be valued at the rates and prices set out in the contract if,in the opinion of the engineer,the same shall be applicable.if the contract does not contain any rates or prices applicable to the extra or additional work,then suitable rates or prices shall be agreed upon between the engineer and the contractor.in the event of disagreement the engineer shall fix such rates or prices as shall,in his opinion,be reasonable and proper.
52.1凡由工程师命令增减的工程,如工程师认为可行,均应按合同价格予以估价。如合同所列的价格不适用所增减的工程,应由工程师和承包人协商出合适的价格。如不能就此达成协议,应由工程师决定一个他认为恰当的价格。
(2)provided that if the nature or amount of any omission or addition relative to the nature oramount of the whole of the works or to any part thereof shall be such that,in the opinion of the engineer,the rate or price contained in the contract for any item of the works is,by reason of such omission or addition,rendered unreasonable or inapplicable,then a suitable rate or price shall
be agreed upon between the engineer and the contractor.in the event of disagreement the engineer shall fix such other rate or price as shall,in his opinion,be reasonable and proper having regard to the circumstances、
52.2如工程师认为,涉及整个工程或部分工程的质或量的增减,使得本合同中所列的任何工程项目的价格因此种增减而不再合理或不切实际,工程师和承包人则应协商一个合适的价格。如不能就此达成协议,应由工程师决定一个他认为恰当的价格。
provided also that no increase or decrease under sub-clause(1)of this clause or variation of rate or price under sub-clause(2)of this clause shall be made unless,as soon after the date of the order as is practicable and,in the case of extra or additional work,before the commencement of the work or as soon thereafter as is practicable,notice shall have been given in writing:
(a)by the contractor to the engineer of his intention to claim extra payment or a varied rate
or price,or
(b)by the engineer to the contractor of his intention to vary a rate or price.
除非在命令作出之后,如是额外或增加工程,则在工程动工前或之后尽快以书面形式:
a)由承包人通知工程师他要求额外支付或更改价格,
b)或由工程师通知承包人他打算改变价格,
否则不得按本条第1款增加或减少工程量,或按本条第2款变动价格。
(3)if,on certified completion of the whole of the works it shall be found that a reduction or increase greater than per cent of the sum named in the letter of acceptance,excluding allfixed sums,provisional sums and allowance for day works,if any,results from:
52.3竣工验证时,如发现增减工程的费用超过验收证书所注明数额的_______%,除去所有的规定费用、临时费用和零工补贴外,如有任何是因:
(a) the aggregate effect of all variation orders,and
变动命令累计所致,以及因
(b)all adjustments upon measurement of the estimated quantities set out in the bill of quantities,excluding all provisional sums,day works and adjustments of price made under clause 70(1)hereof,
修正建筑工程清单所列的估算工程量所致,所有临时费用、零工补贴和本合同第70条第1款规定的价格调整除外,
but not from any other cause,the amount of the contract price shall be adjusted by such sum as may be agreed between the contractor and the engineer or,failing agreement,fixed by the engineer having regard to all material and relevant factors,including the contractor's site and general overhead costs of the contract.
若非其他原因,合同价格应由承包人和工程师协商予以调整,或,如协商不果,则由工程师在考虑所有材料及相关的,包括承包人的场地及合同的一般间接费用在内的因素的基础上予以决定。
(4)the engineer may,if,in his opinion it is necessary or desirable,order in writing that
any additional or substituted work shall be executed on a day-work basis.the contractor shall
then be paid for such work under the conditions set out in the day-work schedule included in the
contract and at the rates and prices affixed thereto by him in his tender.
52.4如工程师认为有必要,可书面命令将增加或替换的工程按零工计价。此种工程承包人所得报酬应根据合同中的零工细目表的条件,按其标书中所附的价格予以支付。
the contractor shall furnish to the engineer such receipts or other vouchers as may be necessary to prove the amounts paid and,before ordering materials,shall submit to the engineer quotations for the same for his approval.
承包人应向工程师提供必要的收据或其他凭证以证实其支出,并应在订材料之前,向工程师提交报价单以求批准。
in respect of all work executed on a day-work basis,the contractor shall,during the continuance of such work,deliver each day to the engineer's representative an exact list in duplicate of the names,occupation and time of all workmen employed on such work and a statement,also in duplicate,showing the description and quantity of all materials and plant used thereon or therefor(other than plant which is included in the percentage addition in accordance with the schedule hereinbefore referred to).one copy of each list and statement will,if correct, or when agreed,be signed by the engineer's representative and returned to the contractor.
所有按零工计价的工程,在工程进行期间,承包人必须每天向工程师代表提供详细清单,一式两份,注明此种工程雇用的所有零工的姓名、职务和工作时间,以及两份说明书,标明用于工程的材料和设备的规格、数量(按上述细目表纳入增加费用计算内的设备除外)。如清单和说明书正确无误,工程师代表将认同且在其中一份上签字,然后退还给承包人。
at the end of each month the contractor shall deliver to the engineer's representative a priced statement of the labor,material and plant,except as aforesaid,used and the contractor shall not be entitled to any payment unless such lists and statements have been fully andpunctually rendered.provided always that if the engineer shall consider that for any reason the sending of such lists or statements by the contractor,in accordance with the foregoing provision, was impracticable he shall nevertheless be entitled to authorize payment for such work,either as day-work,on being satisfied as to the time employed and plant and materials used on such work or at such value therefore as shall,in his opinion,be fair and reasonable.
每月底,承包人应向工程师代表提交一份所使用的劳力、材料和设备(上述规定的除外)的价目清单,如不按时提供完整的价目清单,承包人将无权得到支付。如工程师有理由认为承包人无法按上述规定提交清单,他将有权决定把此种工作或作为零工,按工时及使用的材料和设备进行支付,或按他认为公平合理的价格予以支付。
(5)the contractor shall send to the engineer's representative once in every month an account giving particulars,as full and detailed as possible,of all claims for any additional payment to which the contractor may consider himself entitled and of all extra or additional work ordered by the engineer which he has executed during the preceding month,
52.5承包人应每月向工程师代表提交一报告,尽可能全面详尽地索要他所认为有权要求的一切额外费用,以及陈述上月他按工程师的命令所作的一切额外工作。
no final or interim claim for payment for any such work or expense will be considered which has not been included in such particulars.provided always that the engineer shall be entitled to authorize payment to be made for any such work or expense,notwithstanding the contractor's failure to comply with this condition,if the contractor has,at the earliest practicable opportunity,notified the engineer in writing that he intends to make a claim for such work.
凡未包括在报告中的工作或费用不能在中期或最后给予支付。但如承包人在最初曾书面通知工程师他想就此种工作要求索赔,即使他未遵守上述规定,工程师也有权要求对此种工作或费用给予支付。
plant,temporary works and materials
设备、临建工程和材料
53.(1)all constructional plant,temporary works and materials provided by the contractor shall,when brought on to the site,be deemed to be exclusively intended for the execution of the works and the contractor shall not remove the same or any part thereof,except for the purpose of moving it from one part of the site to another,without the consent,in writing,of the engineer,which shall not be unreasonably withheld.
53.1承包人所提供的所有建筑设备、临建工程设施和材料抵达工地后,应视作完全用于施工,承包人不得移动它们或其任何部分,经工程师书面同意,将它们从工地一端移到另一端除外,工程师不得无故不予同意。
(2)upon completion of the works the contractor shall remove from the site all the said constructional plant and temporary works remaining thereon and any unused materials provided by the contractor.
53.2工程完工后,承包人应从工地将所有上述建筑设备、临建工程设施及按合同所提供的材料的剩余部分清理走。
(3) the employer shall not at any time be liable for the loss of or damage to any of the said constructional plant, temporary works or materials or as mentioned in clauses 20 and 65 hereof.
53.3业主对上述建筑材料、临建工程及材料的损失或损坏概不负责,本合同第20和第65条规定的除外。
(4)in respect of any constructional plant which the contractor shall have imported for the purposes of the works,the employer will assist the contractor,where required,in procuring any necessary government consent to the re-export of such constructional plant by the contractor upon the removal thereof as aforesaid.
53.4如承包人因工程所需而要进口任何建筑设备,业主必须应承包人要求协助其从政 府处得到必要的许可,以便按上述规定清理现场时重新出口此种建筑设备。
(5)the employer will assist the contractor,where required,in obtaining clearance through
the customs of constructional plant,materials and other things required for the works.
53.5业主应在需要时协助承包人为工程所需的建筑设备、材料和其他物品结关。
(6)any other conditions affecting constructional plant,temporary works and materials,shall be set out in part 11 in the clause numbered 53 as may be necessary.
53.6其他任何影响建筑设备、临建工程设施和材料的条件必要时应在第二部分的第53条予以规定。
54.the operation of clause 53 hereof shall not be deemed to imply any approval by the engineer of the materials or other matters referred to therein nor shall it prevent the rejection of any such materials at any time by the engineer.
54.本合同第53条的执行不得视为默示工程师认可该条款所指的材料或其他事项,也不得妨碍工程师在任何时候拒绝使用任何此种材料。
measurement
测定
55.the quantities set out in the bill of quantities are the estimated quantities of the work,but they are not to be taken as the actual and correct quantities of the works to be executed by the contractor in fulfillment of his obligations under the contract.
55.建筑工程清单所列的工程量为估计数量,不应视为是承包人履行合同义务所完成的实际工程量。
56.the engineer shall,except as otherwise stated,ascertain and determine by measurement the value in terms of the contract of work done in accordance with the contract.he shall,when he requires any part or parts of the works to be measured,give notice to the contractor's authorized agent or representative,who shall forthwith attend or send a qualified agent to assist the engineer or the engineer's representative in making such measurement,and shall furnish all particulars required by either of them.should the contractor not attend,or neglect or omit to send such agent,then the measurement made by the engineer or approved by him shall be taken to be the correct measurement of the work.for the purpose of measuring such permanent work as is to be measured by records and drawings,the engineer's representative shall prepare recordsand drawings month by month of such work and the contractor,as and when called upon to do soin writing,shall,withinz _______ days,attend to examine and agree such records and drawings with the engineer's representative and shall sign the same when so agreed.if the contractor does not so attend to examine and agree such records and drawings,they shall be taken to be correct. if,after examination of such records and drawings,the contractor does not agree the same or does not sign the same as agreed,they shall nevertheless be taken to be correct,unless the contractor days of such examination,lodge with the engineer's representative,for decision by the engineer,notice in writing of the respects in which such records and drawings are claimed by him to be incorrect.
56.如无另行规定,工程师应通过测定判断按合同所完成的工程的价值。如他要求对某部分或某些工程进行测定,他应通知承包人的授权代理人或代表,该代理人或代表应立即参加或派一名合格的代理人协助工程师或工程师代表进行此种测定,并提供工程师或其代表所要求的一切详细情况。倘若承包人未参加或忽略或忘记派代理人协助,工程师所作的测定或他认可的测定,应被视为是对工程所作的正确测定。如永久性工程是靠记录和图纸进行测定,工程师代表应按月准备记录和图纸,如应书面要求,承包人应当在xx天内与工程师代表一起检查并认可此种记录和图纸,一经认可,承包人应在记录和图纸上签字。如果承包人不参与检查,记录和图纸应被视为正确无误。如检查完此种记录和图纸后,承包人不予认可或虽认可但不签字,该记录和图纸仍应被视为正确无误,除非承包人在此种检查后xx天内书面告知工程师代表,他认为记录和图纸中哪些不正确,并要求工程师予以裁决。
57.the works shall be measured net,notwithstanding any ganeral or local custom,except where otherwise specifically described or prescribed in the contract.
57.工程测定应采用净值,不管一般习惯或当地惯例如何,本合同另有明文规定的除外。
provisional sums
暂列款
58.(1)“provisional sum' means a sum included in the contract and so designated in the bill of quantities for the execution of work or the supply of goods,materials,or services,or for contingencies,which sum may be used,in whole or in part,or not at all,at the direction and discretion of the engineer.the contract price shall include only such amounts in respect of the work,supply or services to which such provisional sums relate as the engineer shall approve or determine in accordance with this clause.
58.1“暂列款”是指合同中规定且列在建筑工程清单上的,按工程师的指令及自由处置的一笔用于施工、提供货物、材料或服务或用于 意外事故 的金额,可全部或部分使用,或根本不用。凡涉及与暂列款有关的工程、供应或服务的款项,只有经工程师按本合同规定同意或决定使用的方能列人合同价格。
(2)in respect of every provisional sum the engineer shall have power to order:
58.2就每一笔备用款,工程师有权命令用于:
(a)work to be executed,including goods,materials or services to be supplied by the contractor.the contract price shall include the value of such work executed or such goods, materials or services supplied determined in accordance with clause 52 hereof.
施工,包括应由承包人提供的货物、材料或服务。合同价格应包括按合同第52条规定用于此种施工或提供的货物、材料或服务的费用。
(b)work to be executed or goods,materials or services to be supplied by a nominated sub-contractor as hereinafter defined.the sum to be paid to the contractor therefor shall be determined and paid in accordance with clause 59(4)hereof.
由下文所规定的指定转包人的施工,提供的货物、材料或服务。由此付给承包人的款项应按本合同第59条第4款的规定确定并支付。
(c)goods and materials to be purchased by the contractor.the sum to be paid to the contractor therefor shall be determined and paid in accordance with clause 59(4)hereof.
承包人所购买的货物和材料。由此支付给承包人的款项应按本合同第59条第4款确定并支付。
(3)the contractor shall,when required by the engineer,produce all quotations,invoices,
vouchers and accounts or receipts in connection with expenditure in respect of provisional sums.
58.3凡工程师要求,承包人应提供与暂列款有关的开支的所有报价单、发票、凭证、账目或收据。
nominated sub-contractors
指定分包人
59.(1)all specialists,merchants,tradesmen and others executing any work or supplying any goods,materials or services for which provisional sums are included in the contract,who may have been or be nominated or selected or approved by the employer or the engineer,and all persons to whom by virtue of the provisions of the contract the contractor is required to sub-let any work shall,in the execution of such work or the supply of such goods,materials or services, be deemed to be sub-contractors employed by the contractor and are referred to in this contract
as“nominated sub-contractors”.
59.1所有在合同暂列款项下施工或提供任何货物、材料或服务的已由或将由业主或工程师指定或挑选的专家、商人、手工工人和其他人,以及所有根据合同规定,得到承包人任何分包工程且由此施工、提供货物、材料或服务的人,均应被视为是由承包人雇用的转包人,在本合同中称为“指定分包人”。
(2)the contractor shall not be required by the employer or the engineer or be deemed to be under any obligation to employ any nominated sub-contractor against whom the contractor may raise reasonable objection,or who shall decline to enter into a sub-contract with the contractor containing provisions:
59.2承包人不得因业主或工程师的要求,或被认为有任何义务而雇用其有理由反对的,或不与其签署含有下列规定的合同的指定分包人:
(a)that in respect of the work,goods,materials or services the subject of the sub-contract,the nominated sub一contractor will undertake towards the contractor the like obligations and liabilities as are imposed on the contractor towards the employer by the terms ofthe contract and will save harmless and indemnify the contractor from and against the same and from all claims,proceedings,damages,costs,charges and expenses whatsoever arising out of or in connection therewith,or arising out of or in connection with any failure to perform such obligations or to fulfil such liabilities,and
就工程、货物、材料或服务,转包 合同当事人 ,即指定分包人将对承包人承担本合同所规定的承包人应对业主承担的同样的义务和责任,并不让承包人再履行此义务和责任,且不让其受因履行此种义务和责任而产生或与之有关的,或因不履行此种义务或责任而产生或与之有关的一切索赔、诉讼、损害赔偿金、诉讼费、开支和费用的损害,以及
(b)that the nominated sub-contractor will save harmless and indemnify the contractor from and against any negligence by the nominated sub-contractor,his agents,workmen and servants and from and against any misuse by him or them of any constructional plant or temporary works provided by the contractor for the purposes of the contract and from all claims as aforesaid.
指定分包人应使承包人不因指定分包人、其代理人、工人和雇员的过失而受任何损害,不因分包人、其代理人、工人和雇员不当使用承包人按合同所提供的工程设备或临建工程而受损害,以及不因上述所有的索赔而受损害。
(3)if in connection with any provisional sum the services to be provided include any matter of design or specification of any part of the permanent works or of any equipment or plant to be incorporated therein,such requirement shall be expressly stated in the contract and shall be included in any nominated sub-contract.the nominated sub-contract shall specify that the nominated sub-contractor providing such services will save harmless and indemnify the contractor from and against the same and from all claims,proceedings,damages,costs,charges and expenses whatsoever arising out of or in connection with any failure to perform such obligations or to fulfil such liabilities.
59.3如暂列款项下所提供的服务包括任何设计事项或对任何一部分永久性工程的详细规定,或说明工程所使用的任何设备的规格,此种要求应在合同中明文规定,且写进指定分包合同。指定分包合同应明确规定,提供此种服务的指定分包人应不让承包人承担此种服务,且不让承包人因未履行此种义务或因履行此种义务而引起的或有关的任何索赔、诉讼、损害赔偿金、诉讼费、开支和费用而受损害。
(4)for all work executed or goods,materials,or services supplied by any nominated sub-contractor,there shall be included in the contract price.
59.4就指定分包人所进行的所有施工,提供的货物、材料或服务而言,应纳人合同价格中的有:
(a) the actual price paid or due to be paid by the contractor,on the direction of the engineer,and in accordance with the sub-contract:
按工程师的指令及根据分包合同,已实际由或应由承包人支付的款项;
(b) the sum,if any,entered in the bill of quantities for labor supplied by the contractor in connection therewith,or if ordered by the engineer pursuant to clause 58(2)(b)hereof,as may be determined in accordance with clause 52 hereof;
涉及建筑工程清单中所列的(如果有)由承包人提供劳务的,或可能由工程师按本合同第58条第2款所命令的,且可根据本合同第52条确定的款项;
(c)in respect of all other charges and profit,a sum being a percentage rate of the actual price paid or due to be paid calculated,where provision has been made in the bill of quantities for a rate to be set against the relevant provisional sum,at the rate inserted by the contractor against that item or,where no such provision has been made,at the rate inserted by the contractor in the appendix to the tender and repeated where provision for such is made in a special item provided in the bill of quantities for such purpose.
就所有其他费用和收益而言,应采用用一百分比率乘以实际支付或即将支付的款额所得出款项计算,如建筑工程清单已有对有关暂定款列定一个比率的规定,则应按承包人就该项目列定的比率予以计算,如无此种规定,则应按承包人在标书附录所列的,且建筑工程清单已就该具体项目作出认可的比率计算。
(5)before issuing,under clause 60 hereof,any certificate,which includes any payment in respect of work done or goods,materials or services supplied by any nominated sub-contractor, the engineer shall be entitled to demand from the contractor reasonable proof that all payments,less retention,included in previous certificates in respect of the work or goods,materials or services of such nominated sub-contractor have been paid or discharged by the contractor,in default whereof unless the contractor shall:
59.5在按本合同第65条出具任何证书前,若其包括有关任何指定分包人所完成的工程,提供的货物、材料或服务的任何付款,工程师有权要求承包人提供充足 证据 ,证明包括在先前证书中的有关该指定分包人的工程或货物、材料或服务的付款,已全部由承包人支付或清偿,否则将视为拖欠,除非承包人:
(a) inform the engineer in writing that he has reasonable cause for withholding or refusing to make such payments and
书面通知工程师,他有充足理由不予或拒绝此种付款支付,且
(b)produce to the engineer reasonable proof that he has so informed such nominated sub-contractor in writing,
向工程师提供充足证据,证明他已就此书面通知该指定分包人,
the employer shall be entitled to pay to such nominated sub-contractor direct,upon the certificate of the engineer,all payments,less retention,provided for in the sub-contract, which the contractor has failed to make to such nominated sub-contractor and to deduct by way of set-off the amount so paid by the employer from any sums due or which may become due from the employer to the contractor.
业主有权在工程师出具证书后,向该指定分包人直接支付按规定应由承包人向该指定分包人支付,然而却没有支付的所有款项,留置款除外,然后从业主应支付或即将支付给承包人的任何款项中将此笔付款抵销。
provided always that,where the engineer has certified and the employer has paid direct as aforesaid,the engineer shall in issuing any further certificate in favor of the contractor deduct from the amount thereof the amount so paid,direct as aforesaid,but shall not withhold or delay the issue of the certificate itself when due to be issued under the terms of the contract.
如工程师已出具证书,且业主已直接作出上述支付,工程师在向承包人出具任何其他证书,应把业主直接支付的上述款项扣出,但工程师不得拒绝或延误出具按本合同规定应出具的证书本身。
(6)in the event of a nominated sub-contractor,as hereinbefore defined,having undertaken towards the contractor in respect of the work executed,or the goods,materials or services supplied by such nominated sub-contractor,any continuing obligation extending for a period exceeding that of the period of maintenance under the contract,the contractor shall at any time after the expiration period of maintenance,assign to the employer,at the employer's request and cost,the benefit of such obligation for the unexpired duration thereof.
59.6如上所规定,如果指定分包人在施工,或提供货物、材料、或服务中对承包人承担的义务期限超过本合同所规定的维修期,承包人应在维修期满后,随时把此种义务在期满前所产生的利益应业主的要求转让给业主,费用由业主承担。
certificates and payment
证书和付款
60.(1)unless otherwise provided, payment shall be made at monthly intervals in accordance with the conditions set out in part ii in the clause numbered 60.
60.1除另有规定外,付款应按第二部分第60条的规定,分月进行。
(2)where advances are to be made by the employer to the contractor in respect of constructional plant and materials,the conditions of payment and repayment shall be as set out in part ii in the clause numbered 60.
60.2如业主向承包人预付有关建筑设备和材料的款项,付款和还款的条件应在第二部分第60条中予以规定。
(3)if the execution of the works shall necessitate the importation of materials,plant or equipment from a country other than that in which the works are being executed,or if the works or any part thereof are to be executed by labor imported from any other such country,or if any other circumstances shall render it necessary or desirable,a proportion of the payments to be made under the contract shall be made in the appropriate foreign currencies and in accordance with the provisions of clause 72 hereof.the conditions under which such payments are to be made shall be as set out in part ii in the clause numbered 60.
60.3如因施工需从施工所在地国的他国进口材料、设备,或因工程或任何部分工程需由此种他国输入的劳务完成,或因任何其他情况必需或必要,合同项下的某部分付款需按本合同第72条的规定用有关外汇进行支付,支付条件应按合同第二部分第60条的规定处理。
61.no certificate other than the maintenance certificate referred to in clause 62 hereof shall be deemed to constitute approval of the works.
61.除本合同第62条所述的维修证书外,任何证书不得视为是对工程的认可。
62.(1)the contract shall not be considered as completed until a maintenance certificate shall have been signed by the engineer and delivered to the employer stating that the works have been completed and maintained to his satisfaction.the maintenance certificate shall be given by the engineer within days after the expiration of the period of maintenance,or,ifdifferent periods of maintenance shall become applicable to different sections or parts of the works,the expiration of the latest such period,or as~thereafter as any works ordered during such period,pursuant to clause 49 and 50 hereof,shall have been completed to the satisfaction of the engineer and full effect shall be given to this clause,notwithstanding any previous entry on the works or the taking possession,working or using thereof or any part thereof by the employer.provided always that the issue of the maintenance certificate shall not be a condition precedent to payment to the contractor of the second portion of the retention money in accordance with the conditions set out in part ii in the clause numbered 60.
62.1只有工程师签发了维修证书且交给业主,说明工程已完工,维修情况令他满意,才能视合同已经完全履行。工程师应在维修期满后,或,如工程的不同部分适用不同的维修期,在最后一个维修期满后xx天内签发维修证书,或在所有在此维修期中,按本合同第49和第50条规定,命令进行的工程完成且令工程师满意后立即签发,本条款必须全面执行,不管先前业主是否已进人、占有或使用工程或工程的任何部分。维修证书的签发不得作为按第二部分第60条的规定向承包人支付第二笔留置款的前提条件。
(2)the employer shall not be liable to the contractor for any matter or thing arising out of or in connection with the contract or the execution of the works,unless the contractor shall have made a claim in writing in respect thereof before the giving of the maintenance certificate under this clause.
62.2业主不得因本合同或施工所产生或与之有关的任何事项对承包人负责,除非承包人在签发本条款规定的维修证书前,就此种事项已提出书面索赔。
(3)notwithstanding the issue of the maintenance certificate the contractor and,subject to subclause(2)of this clause,the employer shall remain liable for the fulfillment of any obligation incurred under the provisions of the contract prior to the issue of the maintenance certificate which remains unperformed at the time such certificate is issued and,for the purposes of determining the nature and extent of any such obligation,the contract shall be deemed to remain in force between the parties hereto.
62.3尽管签发了维修证书,承包人以及业主(但应符合本条第2款的规定)仍应对发生在证书签发前而在证书签发时尚未履行的合同义务负责,为决定此种义务的性质及范畴,应本合同继续对合同双方有效。
remedies and powers
补救和权力
63.(1)if the contractor shall become bankrupt,or have a receiving order made against him,or shall present his petition in bankruptcy,or shall make an arrangement with or assignment in favor of his creditors,or shall agree to carry out the contract under a committee of inspection of his creditors or,being a corporation,shall go into liquidation(other than a voluntary liquidation for the purposes of amalgamation or reconstruction),or if the contractor shall assign the contract,without the consent in writing of the employer first obtained,or shall have an execution levied on his goods,or if the engineer shall certify in writing to the employer that inhis opinion the contractor:
63.1如果承包人破产,或被法院下达破产者产业管理接收令,或递交破产申请,或与 债权人 签订清偿协议或进行 债权转让 ,或同意在债权人决议委任的破产监督委员会监督下执行本合同,或,如其是一个公司,将被 清算 (不是因合并或重组而进行的自愿清算),或承包人事先未征得业主的书面同意而 转让合同 ,或其货物被扣押,或工程师书面向业主证明,他认为承包人:
(a) has abandoned the contract,or
已经撤销合同,或
(b)without reasonable excuse has failed to commence the works or has suspended the progress of the works for__ days after receiving from the engineer written notice to proceed,or
没有正当理由但却不开工,或在收到工程师要求继续工程的书面通知后,停工_______天,或
(c)has failed to remove materials from the site or to pull down and replace work for
days after receiving from the engineer written notice that the said materials or work had been condemned and rejected by the engineer under these conditions,or
在收到工程师书面通知,说明某些材料不适用或某工程应予否决后_______天内未从工地搬走这些材料,或未拆毁此种工程重建,或
(d)despite previous warnings by the engineer,in writing,is not executing the works in accordance with the contract,or is persistently or flagrantly neglecting to carry out his obligations under the contract,or
不按合同施工,或长期或公然不履行其合同义务,尽管工程师已书面提出 警告 ,或
(e) has,to the detriment of good workmanship,or in defiance of the engineer's instructions to the contrary,sub-let any part of the contract,
不顾工作质量,或无视工程师的指示,转包任何合同部分,
then the employer may,after giving _______days’notice in writing to the contractor,enter upon the site and the works and expel the contractor therefrom without thereby voiding the contract,or releasing the contractor from any of his obligations or liabilities under the contract or affecting the rights and powers conferred on the employer or the engineer by the contract, and may himself complete the works or may employ any other contractor to complete the works. the employer or such other contractor may use for such completion so much of the constructional plant,temporary works and materials,which have been deemed to be reserved exclusively for the execution of the works,under the provisions of the contract,as he or they may think proper,and the employer may,at any time,sell any of the said constructional plant,temporary works and unused materials and apply the proceeds of sale in or towards the satisfaction of any sums due or which may become due to him from the contractor under the contract.
此时,业主可在书面通知承包人_______天后进驻工地,并将承包人逐出,由此不会造成 合同无效 ,或解除承包人的任何合同义务或责任,或影响合同赋予业主或工程师的权利和权力,业主可自己完成工程或另雇其他承包人完成工程。为完成工程,业主和其他承包人可充分使用其认为合适的,按本合同规定被视为是专门为施工而保留的建筑设备、临建工程和材料,业主可随时出售上述任何建筑设备、临建工程和未使用的材料,并将出售收人抵付按合同规定承包人应支付或可能支付给他的任何款项。
(2)the engineer shall,as soon as may be practicable after any such entry and expulsion by the employer,fix and determine ex parte,or by or after reference to the parties,or after such investigation or inquiries as he may think fit to make or institute,and shall certify what amount, if any,had at the time of such entry and expulsion been reasonably earned by or would reasonably accrue to the contractor in respect of work then actually done by him under the contract and the value of any of the said unused or partially used materials,any constructional plant and any temporary works.
63.2业主进驻工地并逐走承包人之后,工程师应尽快单方面,或通过了解双方当事人,或在作过他所认为恰当的调查或咨询之后作出安排或决定,并证明到此种进驻与被逐时为止,按事实上已完成的合同工程,承包人已获得或理应获得的款项(如果有),以及计算出上述任何未使用或只部分使用的材料、建筑设备和临建工程的价值。
(3)if the employer shall enter and expel the contractor under this clause,he shall not be liable to pay to the contractor any money on account of the contract until the expiration of the period of maintenance and thereafter until the costs of execution and maintenance,damages for delay in completion, if any,and all other expenses incurred by the employer have been ascertained and the amount thereof certified by the engineer.the contractor shall then be entitled to receive only such sum or sums,if any,as the engineer may certify would have been payable to him upon due completion by him after deducting the said amount.if such amount shall exceed the sum which would have been payable to the contractor on due completion by him,then the contractor shall,upon demand,pay to the employer the amount of such excess and it shall be deemed a debt due by the contractor to the employer and shall be recoverable accordingly.
63.3如果业主按本条规定进驻工地并逐走承包人,他应在维修期满,且所有施工和维修费、延误完工赔偿费(如果有)、和业主所发生的其他费用被核实,且经工程师证明后,方才负责对承包人按合同进行支付。此时,承包人有权得到的款额(如果有)仅为工程师证明,因他妥善完工而应得的款额减去上述款项之差。如上述费用超过承包人妥善完工应得的款额,经要求,承包人得向业主支付此超出部分款额,超出部分应视为承包人对业主的负债,且可照此收回。
64.if,by reason of any accident,or failure,or other event occurring to in or in connection with the works,or any part thereof,either during the execution of the works,or during the period of maintenance,any remedial or other work or repair shall,in the opinion of the engineer or the engineer's representative,be urgently necessary for the safety of the works and the contractor is unable or unwilling at once to do such work or repair,the employer may employ and pay other persons to carry out such work or repair as the engineer or the engineer's representative may consider necessary.if the work or repair so done by the employer is work which,in the opinion of the engineer,the contractor was liable to do at his own expense under the contract,all expenses properly incurred by the employer in so doing shall be recoverable from the contractor by the employer,or may be deducted by the employer from any monies due or which may become due to the contractor.provided always that the engineer or the engineer's representative,as the case may be,shall,as soon after the occurrence of any such emergency as may be reasonably practicable,notify the contractor thereof in writing.
64.如在施工或维修期间,因工程或部分工程发生或涉及任何意外、或事故、或其他事件,工程师或工程师代表认为需马上进行补救或其他工作或修理,以保证工程的安全,而承包人无法或不愿马上进行此种工作或修理,业主可雇用并支付他人进行工程师或工程师代表认为必要的此种工作或修理。如工程师认为,业主所进行的此种工作属于承包人按合同规定应自己付费完成的工作,业主由此所发生的一切费用应由业主向承包人收回,或从其应付给或可能应付给承包人的款项中扣除。在此种任何紧急事件发生后,工程师或工程师代表应根据情况,尽快书面告知承包人。
special risks
特定风险
65.notwithstanding anything in the contract contained:
65.本合同任何条款均服从以下规定:
(1)the contractor shall be under no liability whatsoever whether by way of indemnity or otherwise for or in respect of destruction of or damage to the works,save to work condemned under the provisions of clause 39 hereof prior to the occurrence of any special risk hereinafter mentioned,or to property whether of the employer or third parties,or for or in respect of injury or loss of life which is the consequence of any special risk as hereinafter defined.the employer shall indemnify and save harmless the contractor against and from the same and against and from all claims,proceedings,damages,costs,charges and expenses whatsoever arising thereout or in connection therewith.
65.1任何责任,不论属于赔偿或其他,也不论其是有关或涉及工程(以下提及的任何特定风险发生前,已按本合同第39条宣布为不适用的工程除外)、业主或第三当事人的财产的毁坏或损坏,或有关或涉及人员伤亡,只要是因以下所规定的特定风险导致,承包人慨不负责。业主必须保证承包人不受上述情况以及由此所引起的任何索赔、诉讼、损害赔偿金、诉讼费、开支和费用的损害。
(2)if the works or any materials on or near in transit to the site,or any other property of the
contractor used or intended to be used for the purposes of the works,shall sustain destruction or damage by reason of any of the said special risks the contractor shall be entitled to payment for:
65.2如工程或任何在工地、或从附近运往工地的材料,或承包人其他用于或旨在用于工地的任何财产因上述特定风险受到毁坏或损坏,承包人有权得到以下偿付:
(a)any permanent work and for any materials so destroyed or damaged,
因此而被毁坏或损坏的任何永久性工程或材料,
and,so far as may be required by the engineer,or as may be necessary for the completion of the works,on the basis of cost plus such profit as the engineer may certify to be reasonable;
以及,只要工程师要求,或工程完工所必需,按成本费加上工程师证明合理的利润为基准支付;
(b)replacing or making good any such destruction or damage to the works;
恢复或补偿工程被如此毁坏或损坏的部分;
(c)replacing or making good such materials or other property of the contractor used. intended to be used for the purposes of the works.
恢复或补偿承包人用于或旨在于工程的此种材料或其他财产。
(3)destruction,damage,injury or loss of life caused by the explosion or impact whenever and wherever occurring of any mine,bomb,shell,grenade,or other projectile,missile, munitions,or explosive of war,shall be deemed to be a consequence of the said special risks.
65.3因地雷、炸弹、炮弹、手榴弹、或其他射弹、导弹、弹药、或军用炸药的爆炸或冲击(不论时间和地点)所导致的毁坏、损害、受伤或死亡应被视为是上述特定风险的结果。
(4)the employer shall repay to the contractor any increased cost of or incidental to the execution of the works,other than such as may be attributable to the cost of reconstructing work condemned under the provisions of clause 39 hereof,prior to the occurrence of any special risk, which is howsoever attributable to or consequent on or the result of or in any way whatsoever connected with the said special risks,subject however to the provisions in this clause hereinafter contained in regard to outbreak of war,but the contractor shall as soon as any such increase of cost shall come to his knowledge forthwith notify the engineer thereof in writing.
65.4除本条以下关于战争爆发的规定外,业主应偿还承包人因上述特定风险而发生的 任何施工额外或附加费用,在任何特定风险发生前按合同第39条视为不适用的工程的重建费不在此列,承包人一旦知道此种费用增加,必须立即书面通知工程师。
(5)the special risks are war,hostilities(whether war be declared or not),invasion,act of foreign enemies,the nuclear and pressure-waves risk described in clause 20(2)hereof,or insofar as it relates to the country in which the works are being or are to be executed or maintained,rebellion,revolution,insurrection,military or usurped power,civil war,or,unless solely restricted to the employees of the contractor or of his sub-contractors and arising from the conduct of the works,riot,commotion or disorder.
65.5特定风险指战争、战争状态(不论宣战予否)、侵略、外国敌对行为、本合同第20条第2款规定的核危险和声波风险、或与正在或即将施工或维修的工程所在地国有关的反叛、革命、暴动、军事政变、篡权、内战,或(只是由承包人或其转包人的雇员和因施工引起的除外)骚乱、动乱或混乱。
(6)if,during the currency of the contract,there shall be an outbreak of war,whether war is declared or not,in any part of the world which,whether financially or otherwise,materially affects the execution of the works,the contractor shall,unless and until the contract is terminated under the provisions of this clause,continue to use his best endeavors to complete the execution of the works.provided always that the employer shall be entitled at any time after such outbreak of war to terminate the contract by giving written notice to the contractor and, upon such notice being given,this contract shall,except as to the rights of the parties under this clause and to the operation of clause 67 hereof,terminate,but without prejudice to the rights of either party in respect of any antecedent breach thereof.
65.6在合同执行时,如世界任何地方爆发战争,无论宣战与否,是否在财政或其他方面对工程造成了重大影响,除非和在本合同按本条款规定终止前,承包人应继续尽力完成工程。业主在战争爆发后随时有权书面通知承包人终止合同,一旦此种通知发出,除本条所规定的双方权利和第67条的规定外,合同应当终止,但不得损害任何一方与以前任何违约有关的一切权利。
(7)if the contract shall be terminated under the provisions of the last preceding sub-clause, the contractor shall,with all reasonable dispatch,remove from the site all constructional plant
and shall give similar facilities to his sub-contractors to do so.
65.7如合同按上一款规定终止,承包人应迅速从工地移走所有建筑设备,并向其转包人提供同样的转移设施。
(8)if the contract shall be terminated as aforesaid,the contractor shall be paid by the employer,insofar as such amounts or items shall not have already been covered by payments on account made to the contractor,for all work executed prior to the date of termination at the rates and prices provided in the contract and in addition.
65.8如果合同如上终止,就承包人所得的暂付款项中尚未包括的在终止之日前已完成工作的款项,业主应按本合同所规定的价格支付给承包人,此外还应支付:
(a) the amounts payable in respect of any preliminary items,、far as the work or service
comprised therein has been carried out or performed,and a proper proportion as certified by the engineer of any such items,the work or service comprised in which has been partially carried out or performed.
所有有关临时单据应予支付的款项,只要单据所含的工作或服务已经完成,如此种单据所含的工作或服务只完成一部分,则只支付经工程师确认的应予支付的那一部分款项。
(b) the cost of materials or goods reasonably ordered for the works which shall have been delivered to the contractor or of which the contractor is legally liable to accept delivery,such materials or goods becoming the property of the employer upon such payments being made by him.
因工程而订购的材料或货物的合理费用,包括已运交承包人的和承包人按法律有义务接收的材料或货物,业主向承包人付款后,这些材料或货物即成为业主的财产。
(c)a sum to be certified by the engineer,being the amount of any expenditure reasonably incurred by the contractor in the expectation of completing the whole of the works insofar as such expenditure shall not have been covered by the payments in this sub-clause before mentioned.
经工程师确认的,承包人为完成整个工程而发生的合理费用,只要本款上述各种费用未将此费用包括在内。
(d)any additional sum payable under the provisions of sub-clauses(1),(2)and(4)of this clause.
本条第1、第2和第4款所规定的追加付款。
(e)the reasonable cost of removal of constructional plant under sub-clause(7)of this clause and,if required by the contractor,return thereof the contractor's main plant yard in his country of registration or to other destination,at no greater cost.
本条第7款所规定的搬迁建筑设备的合理费用,如果承包人要求,包括将此设备运回到承包人注册国的主要设备堆置场的费用,或运至其他地点的费用,但此费用不得超过运回注册国的费用。
(f) the reasonable cost of repatriation of all the contractor's staff and workmen employed on or in connection with the works at the time of such termination.
合同终止 时,遣返承包人雇用在工程上或与之有关的职员和工人的合理费用。
provided always that against any payments due from the employer under this sub-clause the employer shall be entitled to be credited with any outstanding balances due from the contractor for advances in respect of constructional plant and materials and any other sums which at the date of termination wear recoverable by the employer from the contractor under the terms of the contract.
对本款项下业主应予支付的款项,业主有权用承包人的应付款来抵冲,包括建筑设备及材料的预付款的未偿余额,以及其他任何在合同终止日按合同条款业主有权向承包人回收的款项。
frustration
受挫失效
66.if a war,or other circumstances outside the control of both parties,arises after the contract is made so that either party is prevented from fulfilling his contractual obligations,or under the law governing the contract,the parties are released from further performance,then the sum payable by the employer to the contractor in respect of the work executed shall be the same as that which would have been payable under clause 65 hereof if the contract had been terminated under the provisions of clause 65 hereof.
66.如合同缔结后爆发战争,或出现双方无法控制的其他情况,使得任何一方无法履行其合同义务,或根据合同适用的法律,双方被解除了继续履约的义务,由业主对已完成的工程而支付承包人的款额应当等于按本合同第65条规定之金额,即如果合同根据第65条之规定终止时,应当支付的金额。
settlement of disputes
争议的解决
67.if any dispute or difference of any kind whatsoever shall arise between the employer and the contractor or the engineer and the contractor in connection with,or arising out of the contract,or the execution of the works,whether during the progress of the works or after their completion and whether before or after the termination,abandonment or breach of the contract, it shall,in the first place,be referred to and settled by the engineer who shall,within a period of
_______days after being requested by either party to do so,give written notice of his decision to the employer and the contractor.subject to arbitration,as hereinafter provided,such decision in respect of every matter so referred shall be final and binding upon the employer and the contractor and shall forthwith be given effect to by the employer and by the contractor,who shall proceed with the execution of the works with all due diligence whether he or the employer requires arbitration, as hereinafter provided,or not.if the engineer has given written notice of his decision to the employer and the contractor and no claim to arbitration has been communicated to him by either the employer or the contractor within a period of _______days from receipt of such notice,the said decision shall remain final and binding upon the employer and the contractor. if the engineer shall fail to give notice of his decision,as aforesaid,within a period of _______ days
after being requested as aforesaid,or if either the employer or the contractor be dissatisfied withany such decision,then and in any such case either the employer or the contractor may within _______ days after receiving notice of such decision,or within _______days after the expiration of the first-named period of _______days,as the case may be,require that the matter or matters in dispute be referred to arbitration as hereinafter provided.all disputes or differences in respect of which the decision,if any,of the engineer has not become final and binding as aforesaid shall be finally settled under the rules of conciliation and arbitration of the international chamber of commerce by one or more arbitrators appointed under such rules.the said arbitrator/s shall have full power to open up,revise and review any decision,opinion, direction, certificate or valuation of the engineer.neither party shall be limited in the proceedings before such arbitrator/s to the evidence or arguments put before the engineer for the purpose of obtaining his said decision.no decision given by the engineer in accordance with the foregoing provisions shall disqualify him from being called as a witness and giving evidence before the arbitrator/s on any matter whatsoever relevant to the dispute or difference referred to the arbitrator/s as aforesaid.the reference to arbitration may proceed notwithstanding that the works shall not then be or be alleged to be complete,provided always that the obligations of the employer,the engineer and the contractor shall not be altered by reason of the arbitration being
conducted during the progress of the works.
67.业主与承包人或工程师与承包人因合同或工程施工而发生的或与之有关的任何争议或分歧,无论是在施工中还是在完工后,无论是在合同终止、撤销或违约前后,首先应当提交工程师解决,应任何一方要求后_______天内,工程师必须将其决定书面通知业主和承包人。除按以下规定提出仲裁外,此种有关上述所有事项的决定为最终决定,对业主和承包人均有约束力的,且立即对业主和承包人生效,承包人应继续施工并尽一切应有的注意,无论他或业主或承包人是否要按以下规定提请仲裁。在工程师将决定书面通知业主和承包人后,如_______天内未收到业主或承包人的仲裁申请,上述决定应作为最终决定,对业主和承包人均有约束力。如工程师未按上述规定应要求在_______天内通知其决定,或业主或承包人对此种决定不满意,在此后或此种情况下,业主或承包人可在收到决定通知_______天内,或在最先所说的_______天期满后_______天内,视情况而定,将争议事项按下述规定提交仲裁。所有争议或分歧,凡工程师的有关决定(如果有)如上所述不再是最终和有约束力的,均应由根据《国际商会调解和仲裁规则》所指定的一名或多名仲裁员按该规则规定予以最终解决。上述仲裁员(们)有权评论、修正和复审工程师的任何决定、意见、指示、证书或估价。在仲裁过程中,任何一方均可不受限制地向仲裁员(们)提供当时供工程师作出决定而采用的证据或论据。不论工程师按上述规定曾作过何种决定,均不得剥夺其被 传唤 作为 证人 ,且就按上述规定提交仲裁的争议或分歧的任何有关事项向仲裁员(们)提供证据的资格。不论工程尚未或认为尚未完工,均可提请仲裁,但业主、工程师和承包人的义务不得因在施工进程中提起仲裁而改变。
notice
通知
68.(1)all certificates,notices or written orders to be given by the employer or by the engineer to the contractor under the terms of the contract shall be served by sending by post toor delivering the same to the contractor's principal place of business,or such other address as the contractor shall nominate for this purpose.
68.1业主或工程师按合同条款给予承包人的所有证书、通知或书面命令均应邮寄或送 交至承包人的主要营业地,或承包人指定的其他通讯地址。
(2)all notices to be given to the employer or to the engineer under the terms of the contract shall be served by sending by post or delivering the same to the respective addresses nominated for that purpose in part 11 of these conditions.
68.2所有按本合同条款给予业主或工程师的通知均应邮寄或送交至第二部分有关通知条款所指定的其各自的地址。
(3)either party may change a nominate address to another address in the country where the works are being executed by prior written notice to the other party and the engineer may do so by prior written notice to both parties.
68.3任何一方均可把一指定地址改为在施工地国的另外一个地址,但事先应书面通知另一方,工程师在改变地址前需书面通知双方当事人。
default of employer
业主违约
69.(1)in the event of the employer:
69.1如果业主:
(a)failing to pay to the contractor the amount due under any certificate of the engineer within_______days after the same shall have become due under the terms of the contract,subject to any deduction that the employer is entitled to make under the contract,or
在工程师证书所认定的应付款项按合同条款到期_______天内未向承包人支付,业主按合同有权所作的扣除部分除外,或
(b)interfering with or obstructing or refusing any required approval to the issue of any such
certificate,or
干涉或阻碍或拒绝同意颁发任何此种证书,或
(c)becoming bankrupt or,being a company,going into liquidation,other than for the purpose of a scheme of reconstruction or amalgamation,or
破产或、如为公司,即将被清算,而此种清算不是为了重组或合并,或
(d)giving formal notice to the contractor that for unforeseen reasons,due to economic dislocation,it is impossible for him to continue to meet his contractual obligations.
正式通知承包人,因不可预见的原因,鉴于经济混乱,其无法再履行其合同义务,
the contractor shall be entitled to terminate his employment under the contract after
givingday's prior written notice to the employer,with a copy to the engineer.
承包人应有权在提前xx天书面通知业主,并将副本呈交工程师后,终止其合同雇佣关系。
(2)upon the expiry of the _______ days’notice referred to in sub-clause(1)of this clause,
the contractor shall,notwithstanding the provisions of clause 53(1)hereof,with all reasonable
dispatch,remove from the site all constructional plant brought by him thereon.
69.2本条第1款规定的_______天通知期限到期后,尽管本合同第53条第1款作有规定,承包人仍然应尽量迅速地从工地撤走他所带来的所有建筑设备。
(3)in the event of such termination the employer shall be under the same obligations to the contractor in regard to payment as if the contract had been terminated under the provisions of clause 65 hereof,but,in addition to the payments specified in clause 65(8)hereof,the employer shall pay to the contractor the amount of any loss or damage to the contractor arising out of or in connection with or by consequence of such termination.
69.3如果合同如此终止,业主必须向承包人承担本合同按第65条规定终止时一样的支付义务,但除了第65条第8款所规定的款项外,业主还必须向承包人支付因合同由此终止而造成的或有关的或导致的灭失或损失费。
changes in costs and legislation
费用与法规的变更
70.(1)adjustments to the contract price shall be made in respect of rise or fall in the costs of labor and/or materials or any other matters affecting the cost of the execution of the works,as
set out in part ii in the clause numbered 70.
70.1合同价格的调整应与劳工或/和材料成本的增减,或其他任何影响施工费用的事项相关,应按第二部分第70条规定执行。
(2)if,of ter the date _______days prior to the latest date for submission of tenders for the works there occur in the country in which the works are being or are to be executed changes to any national or state statute,ordinance,decree or other law or any regulation or by一law of any local or other duly constituted authority,or the introduction of any such state statute, ordinance,decree,law,regulation or by-law which causes additional or reduced cost to the contractor,other than under sub-clause(1)of this clause,in the execution of the works such additional or reduced cost shall be certified by the engineer and shall be paid by or credited to the employer and the contract price adjusted accordingly.
70.2在提交工程标书最后期限前的_________天之后,如施工或即将施工工程所在地国的任何国家或州的法规、法令、政令或其他任何地方和其他权力机构的法律或条例或规章发生变化,或适用了使承包人的施工费用发生增减(非本条第1款所述的增减)的任何州的法规法令、政令、法律、条例或规章,此种费用增减应经工程师证明,且由业主支付或记人贷方,合同价格也应作相应调整。
currency and rates of exchange
货币和汇率
71.if,after the date________days prior to the latest date for submission of tenders for the
works the government or authorized agency of the government of the country in which the works are being or are to be executed imposes currency restrictions and/or transfer of currency restrictions in relation to the currency or currencies in which the contract price is to be paid theemployer shall reimburse any loss or damage to the contractor arising therefrom,without prejudice to the right of the contractor to exercise any other rights or remedies to which he is entitled in such event.
71.在提交标书最后期限前的xx天之后,如施工或即将施工工程所在地国的政府或政府授权机构对合同价格计价货币实行货币 管制 和/或货币兑换管制,业主应补偿由此对承包人造成的一切损失或损害,承包人在此种情况下有权行使其他任何权利或补救措施不得由此而受影响。
72.(1)where the contract provides for payment in whole or in part to be made to the contractor in foreign currency or currencies,such payment shall not be subject to variations in the rate or rates of exchange between such specified foreign currency or currencies and the currency of the country in which the works are to be executed.
72.1如果合同规定,承包人的支付应全部或部分使用一种或多种外币,此种支付不得受特定外币与施工工程所在地国的货币间的汇率变化的影响。
(2)where the employer shall have required the tender to be expressed in a single currency but with payment to be made in more than one currency and the contractor has stated the proportions or amounts of other currency or currencies in which he requires payment to be made the rate or rates of exchange applicable for calculating the payment of such proportions or amounts shall be those prevailing,as determined by the central bank of the country in which the works are to be executed,on the date days prior to the latest date for the submission of tenders for the works,as shall have been notified to the contractor by the employer prior to the submission of tenders or as provided for in the tender documents.
72.2如业主要求标书计价只用一种货币,而支付却用多种货币,且承包人已说明他要求用其他货币支付的比例或数额,用于计算此种比例或数额支付的货币兑换率应为现行汇率,即由施工所在地国的中央银行在提交标书最后期限前的xx天当日所决定的汇率,就此,业主必须在标书提交前告知承包人,或在投标文件中予以写明。
(3)where the contract provides for payment in more than one currency,the proportions or amounts to be paid in foreign currencies in respect of provisional sum items shall be determined in accordance with the principles set forth in sub-clause(1)and(2)of this clause as and when these sums are utilized in whole or in part in accordance with the provisions of clause 58 and 59 hereof.
72.3如合同规定使用多种货币支付,凡涉及按本合同第58和第59条规定使用暂列款的项目,其用外汇支付的比例或数额应按本条第1和第2款制定的原则予以确定。
for part i clauses is included hereinafter.
(本部分以下所列规定是对第一部分条款在各种具体情况下的补充或修改。)
(以下略)
一般情况下,需要进行木工安装工程的时候,会请专业的师傅进行。今天小编就给大家整理了承包合同,希望大家来参考哦
木工承包合同书参考
发包方:(以下简称甲方)
承包方: 身份证号: (以下简称乙方)
依照《中华人民共和国建筑法》、《中华人民共和国合同法》,双方本着平等、自愿、互惠互利、协商一致的原则,达成如下协议,双方共同遵守。
一、工程名称:
二、工程地点:
三、承包范围:甲方将项目(图纸后浇带划分)
1、基础、地下室、主体、墙体定位筋、二次结构,所有的施工现场预留洞口与卸料平台搭设。阳台样板、后浇带、雨罩的模板制作、安装、支撑搭设、场内运输、螺杆的购买、止水螺杆、保养、卸货、模板拆除、起钉、模板刷脱模剂、工字钢悬挑层模板封闭、人货电梯的通道平台铺设、材料的码放、回收、清理等图纸所示的全部工作内容
2、工具用具及机械:甲方提供电箱至每层及木工加工场旁,其余设备乙方负责。
四、承包方式:
以包工包料(0以上乙方必须使用三套全新模板)、包材料损耗、包工期、包质量、包安全生产及文明施工、包所有小型工具和手提电动机械、包场内水平、垂直运输、包工程验收,质量达到甲方、监理、建设单位检验的合格标准,(如果相关单位要求对质量有影响必须要更换模板必须更换)包施工时乙方工人的安全保护用品、工伤保险和劳保福利。乙方施工辅助用移动配电箱由甲方统一配置、费用由乙方承担。所有楼层的钢管由甲方提供。
五、结算方式:
1、本工程按照施工图纸、设计变更以及施工现场实际有效的签证单计算工程量,按照承包单价进行结算为达到市级示范质量要求所采取的合理的技术措施和由于乙方的原因造成返工的工程量,甲方不予计量。
2、结算审核程序:乙方申请施工员审核工程量质量员确认质量等级项目核算员审核单价材料员和仓库保管员签证项目经理批准(项目经理有权对有依据的工程量进行增减)项目负责人终批。
3、现场发生的工程签证,须于工程完成后七日内报施工员签证,确认工作内容、工作量、工作时间,经施工员确认后必须在七日内报项目负责人签字确认,逾期不上报的则不予受理,将不纳入工程结算中。
说明:
(1)作为有丰富施工经验的承包方,在签订本合同前已完全充分了解与本工程的施工有关的各种情况和信息,乙方承诺不会因为除本合同条款规定可调整的项目外而向甲方要求额外的费用和其他项目的索赔。
(2)合同履行期间,由于工程变更等各种原因而引起甲方自身的承包范围发生减少,则甲方有权按照实际情况与乙方协商后修改乙方的承包综合单价及承包工程量。
(3)由于乙方的原因造成返工的工程量,甲方不予计量,同时超量耗用的材料费等从乙方的结算款中予以扣除。
六、承包单价:
1、包机械、包铁钉、铁丝、包小型工具用具及手提电动机械,并配合甲方放线员协助放线,按模板接触面积计算,每平方米综合单价为 元/㎡。
2、承包单价为综合单价〔包人工费、材料费、管理费、差旅费、赶工费、医疗费、社保费、医保费、个人所得税及手提用具等费用),木工按模板与混凝土接触面积计算,承包范围以外的工程量确需做点工按照 150 元/点工计价。
3、合同包干价,在工程施工过程中,设计变更洽商在3000元以内不作调增调减。因已施工完毕,再进行变更,按实际工作量签证。
七、付款方式:
(一)支付时间
1、按甲方与开发商签订的节点支付所完成工程量的70%(含已支付的工人生活费),即0.00付一次以后每八层付70%(含已支付的工人生活费)。
2、到春节前甲方支付乙方所完成工程量的80%
3、工程封顶一个月内付至完成量的80%,所有模板完成后三个月内付至完成量的95%,余下5%待竣工验收合格后付清
4、当月如有罚款在支付工程款项中直接扣除。
(二)支付规定
1、从乙方的队伍正式进场后的第二个月开始每月支付工人生活费,每月的支付标准为参照上月上岗工人的平均人数,按照每人每月800元的标准支付。
2、乙方在每次申请工程进度款时,必须将所完成工作量报项目施工员、核算员,项目负责人审核,提供当月上岗工人花名册及工资明细表,交项目部批准。
3、甲方支付款项时采用转账支票与现金各50%的支付形式(乙方不提供发票)
八、双方的职责:
(一)甲方职责:
1、甲方委派 为工地现场代表,负责本合同的履行。
2、进场前五天,甲方必须向乙方签发施工队伍进场通知书,乙方凭进场通知书办理进退场手续及完工结算手续。
3、乙方进场时,甲方以书面形式就公司制度、工地管理制度及具体管理人员名单向乙方交底
4、负责现场施工技术问题的指导和质量监督,及时用书面形式传达作业指导书、安全交底书、施工图纸等技术有关资料。
5、甲方委派的工地现场代表,负责对乙方的工程质量、进度进行检查验收,办理变更登记、竣工结算手续等工作。
6、甲方有权对不服从各部门协调、安排的班组给予罚款或整改的处罚,有权勒令违法、违章经教育无效的乙方作业人员在24小时内离开本项目部。
7、甲方有权在工地内随时抽查乙方工人随身携带物品,如有发现乙方工人有盗窃行为,甲方对乙方处30000~5000元/次罚款,并将乙方工人扭送公安机关处理。
(二)乙方职责:
1、乙方委派 为现场管理代表,负责管理劳务作业人员,并协调和检查、考核各劳务作业班组的各项工作和完成情况并按时参加项目部的月计划会议和工作调会议。乙方责任人每周保证6天(以考勤为准)住在现场且保持通讯24小时畅通,若发现不在现场每天罚款150元,开会迟到罚款50元,不参加罚款200元特殊有事时,需提前向项目经理或现场经理请假,并经允许后方可离开现场,但不得超过2天。
2、乙方进场前必须与工人签订用工协议书,内容包括工程质量、施工安全、管理职责和工资发放等手续协议要求一式三份(乙方、工人、甲方项目部各执一份)。负责作业人员的政治思想、技术培训、职业道德、教育工作。
3、乙方队伍进场时,提供五证,须按当地政府外来人口的有关管理规定,申报办理相关手续,如不办理,发生的一切责任由乙方承担乙方不得雇佣18岁以下及不宜从事建筑工程施工的作业人员,否则发生一切责任,由乙方自行承担。
4、乙方必须确保工资及时发放工资到工人,若因乙方工资发放不及时或发放不到位而造成的劳资纠纷,甲方有权代为处理,处理费用在乙方工程款中扣除并处以1000元/次的罚款。
5、乙方自带必备的施工工具和用具以及工人的安全防护用品等,费用包括在承包单价内。若甲方根据文明施工的要求,需要统一为工人配备安全帽、工作服、工具包等,则甲方有权将此部分的费用按照实际情况从乙方的结算款中予以扣除。
6、乙方应遵循甲方公司的《成品保护的有关规定》,加强对施工人员的成品保护教育,不得在结构物和已施工完成的成品、半成品上随意钻孔、凿槽、拆除结构物等,否则甲方有权按规定从乙方工程款中扣除罚款。
7、乙方不得将承包范围内的工程转包给他人,否则,甲方有权解除合同,乙方向甲方支付合同总价5%的违约金,给甲方造成损失的,必须承担赔偿责任。
8、乙方施工中每天必须做到工完料清以及工程竣工后的场地清理(包括临时生产和生活设施)。
9、乙方新工人进场,必须于二天之内带齐新工人身份证原件和二张一寸照片到甲方项目部办理登记。乙方工人必须持证上岗,如有发现无证上岗,每人每次处以违约金200~300元造成严重安全事故的由乙方承担一切责任,甲方不承担任何责任或义务。
10、严禁乙方工人在工地打架、斗殴、酗酒、闹事、偷窃、破坏公司财产,如有发生,当事者双方均处500~1000元违约金罚款,情节严重者报送公安机关处理。
11、在执行合同期间,乙方对所有发生工程量签证依据的数量、承包同时范围、工作内容必须属实,工程签证必须严格按照甲方的签工要求,同时三人签字方可生效(施工员、核算员、项目经理),如果发现签证单内容有虚假记录串谋作弊等行为,甲方有权按分项工程价款的100%进行处罚。甲方有权终止合同,责令乙方退场,另选施工班组。情节严重者,送司法机关追究刑事责任。
12、乙方施工完毕或中途退场,应在接到甲方书面通知之日起2天内,负责将其所有施工人员、施工机械、机具撤离甲方工地逾期未撤离的,甲方有权采取任何强制措施,强行责令乙方退场,所产生的费用(包括甲方垫付的工人工资等费用)在乙方工程款中扣除,由此造成的经济损失和法律后果均由乙方完全承担,与甲方无关。
13、乙方因自身的原因或者无正当的理由而要求中途退场时,甲方项目部有权按照乙方实际已完成的工程量的60%进行结算。
14、乙方在履行合同的过程中,不得以任何理由和原因,煽动工人闹事、围攻甲方人员和工地办公室。若发生以上情况,甲方有权对乙方处以2000元的罚款并在结算款中予以扣除。
15、如果因为工程发生变更而造成乙方承包范围的工程量的增加或减少,乙方须积极调整劳动力,无条件服从甲方的指挥,不得以此和其他原因为借口,向甲方提出经济补偿和单价调整的要求,否则视为乙方违约。
16、乙方必须服从项目部管理人员的生产、安全、质量安排,如有争议可请示项目经理协商解决,无正当理由不服从安排的将视情节轻重处以1000~5000元/每次的罚款,罚款金额在当月进度款中扣除。
17、乙方必须组织好工人进行施工生产,进行三级安全教育,并及时上报项目部,如有发现无三级安全教育和工人照片,发生一切责任由乙方自行负责并对班组进行300元罚款。
18、乙方手机必须二十四小时开机,如果施工现场需要调节与沟通生产机进度,乙方违约承诺的时间不能到位,按情节轻重给予500~3000元/每次的罚款。
九、定岗定员要求:
1、乙方拟进场的人数应满足现场进度要求。
2、乙方的施工管理应实行定员、定岗制度,按工作量、工期进行定员,按建筑物部位进行定岗。详细的施工小组人员名单在开工前必须报甲方,并上墙公布,如不按此要求执行,甲方对乙方可处以承包产值5%的违约金处罚。
3、甲方有权不定期清点乙方人数,第一次发现每少一人可按90元/人处以违约金罚款第二次按180元/人处以违约金罚款第三次工人仍不到位,甲方有权增派或改派其它施工单位施工,由此增加的承包差价由乙方承担,在乙方工程款中扣除,后责令乙方按已完工程的60%结算退场。
4、乙方必须按甲方的要求定员定岗,如随意调换工人充数,每次处以违约金100元/人。
十、施工工期的条款:
1、按项目部施工进度计划。
2、在工种街接上,承包方必须服从发包方的统一调度,承包方无特殊原因而造成工种街接上的脱节,须赔偿由此造成的一切经济损失。
3、按第2条中的分部分项工程进度计划,每个分项工程计划最终完成时间每延迟1天,甲方有权对乙方处以1000元/节点/天的罚款,按双方确认进度计划延误合计超过3天的,甲方有权另行安排队组进行抢工,由此发生的各项费用,在乙方结算款中予以扣除,或通知乙方解除本合同,有关责任由乙方承担。
4、若乙方的工程进度和工期明显与控制点不符,甲方可要求乙方赶工,若乙方在收到甲方通知1天内无明显改进,或乙方无能力承担工程任务,甲方有权增派或改派其它的施工单位,由此增加的承包价差由乙方承担,在乙方工程款中扣除,同时甲方有权责令乙方按已完成的合格工程的70%工程量结算退场。
5、如遇下述情况,由乙方向甲方在24小时内办理书面的延期签证,但甲方不负担由此引起的费用。
①开工前甲方不能按时交出场地,提供水电的接入点
②业主、建设单位重大设计变更的影响
③不可抗力严重影响施工。
6、乙方已充分考虑到本工程可能由于停电、停水、恶劣天气、业主的工程变更、现场工序的交接不及时以及当地政府对于有关工程施工时间限制的规定等而引起的工期延误,并且乙方不会因为以上原因造成窝工等情况向甲方提出有关费用补贴的要求。
7、若非乙方的原因造成工程连续停工十天(不含不可抗力的原因)以上,甲方应承担乙方实际到岗工人误工费,但补贴费用不超过3万元。 十一、工程质量的条款:
1、乙方承包施工的工程量以gb50300-2001《建筑工程施工质量验收统一彼标准》及相关规范、施工图纸及说明、施工方案、设计变更、技术交底、作为检查、抽查或验收的依据和标准。
2、乙方必须服从甲方管理人员指挥,严格做好工人技术交底,严格按照以上约定的标准进行施工因乙方的原因造成工程出现质量问题,乙方必须无条件、无偿采取相关补救措施,直至消除质量隐患,并赔偿因此给甲方造成的损失,工期不顺延,甲方有权视乙方对施工质量的补救情况决定是否解除合同甲方也可以不要求乙方采取补救措施,直接解除合同,由乙方承担补救费用,并赔偿因此给甲方造成的其他损失。
3、分项工程施工完毕之后,乙方必须先经自检合格后方能书面呈报甲方(或相关单位)验收。甲方第一次验收不合格,对乙方处以500违约金罚款,可考虑要求乙方限期整改完毕后再报甲方验收若乙方未能在限期内整改完毕或虽整改完毕但经甲方第二次验收仍不合格的,甲方有权通知乙方解除本合同,对乙方按已完工合格工程的70%结算,并限期办理有关退场手续。
4、工程质量要求达到甲方、监理、建设单位检验的合格标准,主体结构的楼面质量达清水混凝土的要求。如果要求乙方更换模板没有更换模板经有关单位发现每次罚款2000元。
十二、安全生产和文明施工的条款:
乙方施工过程必须按照工程质量、安全文明双示范工地标准施工。
1、乙方对自有人员的进场必须做好安全、技术三级教育和考核工作,并应将该工作的书面资料及时报送项目部安全员。
2、乙方必须做好每天的班前安全交底及每周安全检查的总结,并有书面记录严格按照现行有关安全操作规程施工,执行公司和工地有关安全生产制度〔处罚标准),用电机具要专人管理专人操作,若违反规定造成工伤事故由乙方负责。
3、施工现场乙方必须有专人负责安全管理和监控工作,及时做好安全的自检和整改工作。
4、严禁乙方工人私自接电线、插座、电炉、煤气、开水龙头不关者,发现每人次处以违约金100元整,从工程款中扣除。
5、乙方自行负责工人的劳保用品、劳保福利及施工过程中乙方所发生的工伤事故处理的一切费用,与甲方无关。
6、特殊工种操作人员必须持有效证件上岗机械的操作人员必须为有丰富经验和经过培训的工人,因为自身违章操作而引起的安全事故,一切责任均由承包方负责。
7、由于乙方施工管理不善,造成任何第三方的损害,由乙方承担一切责任。
8、乙方的工人在施工过程中,必须每天穿着工作服、戴好安全帽,不允许穿拖鞋和赤膊操作,不允许在施工场地内随意大小便,否则甲方有权对以上现象进行经济处罚。
9、乙方施工中每天做到工完料清,及时做好每天施工作业面和材料堆放场地的清理工作。半成品以及废料等应按规格堆放在甲方指定区域内。
10、乙方的工人在施工过程中,若被发现有私自拆除安全设施,包括脚手架、安全网、脚手板以及施工洞口和临边的栏杆、盖板和机械防护设施等现象时,甲方有权按照公司的安全管理规定予以处罚(将按每次300元进行处罚)
11、乙方的施工人员在施工现场必须保持施工场地的卫生整洁,不得乱扔垃圾,否则甲方有权对以上现象进行经济处罚。
12、乙方的工人在上下班的过程中应注意安全,发生任何安全事故均由乙方自行负责,与甲方无任何关系。
13、由于乙方自身的原因发生安全事故,乙方必须服从甲方对于事故的处理方法和程序,并承担相应的责任。
14、乙方内部员工打架斗殴造成的伤害和损害,由乙方自行负责,与甲方无关。
十三、生活区和宿舍管理条款:
1、甲方负责向乙方提供住宿及用膳设施的条件,如果分包人不能按照项目部规定的人数要求居住,则每月按500元/间收取住宿费。
2、乙方的施工人员宿舍必须服从甲方项目部的统一安排,宿舍内保持清洁卫生,注意保护公共设施,损坏和污染各项设施照价赔偿。
3、乙方工人必须留宿工地,工地不得留宿外来人员,违者处以违约金罚款每人每晚50元的标准计算,因此而造成治安问题的,由乙方承担一切责任,甲方不承担任何责任或义务。
4、严禁乙方的工人在宿舍内私自乱拉乱接电线、插座、电炉、煤气生火做饭,若出现以上现象,甲方有权予以无条件拆除,并有权进行经济处罚。若因为以上原因而引起的火灾、触电等安全事故,一切后果均由乙方负责,与甲方无关。
5、乙方住宿区每间房用电装表核量,每月用电量不得大于50度/大房间、30度/小房间,超出额定用量,按1.5元/度收取乙方超用部分电费,从当月生活费中扣除。
6、乙方的工人在生活区洗衣、洗澡等,必须节约用水,开水龙头不关者,发现每人次处以违约金100元整,从工程款中扣除。
7、在食堂买饭菜时,遵循先来后到的原则,讲究礼貌,一律在食堂的窗口依次排队等候,若由此发生打架斗殴等现象,将按照项目部的管理规定进行处罚。
十四、解决合同纠纷的方式:
1、因本合同发生争议时,可由双方友协商解决。
2、如果双方协商不成时,可向合同签订的人民法院起诉。
十五、其他:
1、甲方的现场管理人员工有权根据有关合同条款及管理制度对乙方进行处罚,乙方的代表必须接收签字,不签收者甲方有权直接通知交财务部门从乙方的工程进度款中扣除,另外每次按照50元处以罚款。
2、本合同附件、公司和项目部管理制度以及施工过程中的有关技术、质量、安全的交底内容和相关的项目部会议决定等均作为本合同的附件,具有同等法律效力。
3、合同一式肆份,甲乙双方各执贰份,,均具同等法律效力。
4、本合同依甲方与开发公司签订的合同成立而成立,自双方签字、盖章后生效。
甲方(公章):_________ 乙方(公章):_________
法定代表人(签字):_________ 法定代表人(签字):_________
_________年____月____日 _________年____月____日
有关公司木工承包合同范本
工程名称:商丘名仕华庭3#、4#住宅楼
发包单位: (甲方) 承包单位: 木工组 (乙方) 为了使工程顺利安全进展,依照有关法律法规,在平等、自愿、互惠的基础上,经双方协商一致,就本工程承包事项达成如下协议:
一、承包方式及内容:清包工。施工图纸所包括的全部模板工程(含垫层、基础、圈梁、构造柱、现浇梁板、线条、楼梯、预制构件模板等)
二、承包价格:按照施工图纸建筑面积计算,单价 17 元/m2,一次包清。
三、材料、机械工具的供应及使用:
1、所用模板、木方、架材、机械、主要工具由甲方供应。其它施工用的附属工具(电锯、手锯、铁丝、钉子、锤子、线绳、线锤等)、生活用品、由乙方自行解决。
2、乙方有义务妥善保管使用机械、工具、架材。日常保养、维修的人工费用由乙方承担。不用的材料应保质保量如数交还。无故损坏,乙方负责赔偿。
3、乙方应合理使用材料,现场日日清、日日净,给甲方造成浪费的,将视情节轻重给予处罚。
4、乙方所需材料、机械、工具、架材,必须提前三天书面通知甲方,否则造成工期延误,停工、窝工,后果有乙方自负。
四、工程质量:
1、必须达到施工图纸及国家现行验收规范、地方质量验收标准的要求。 否则,应重新返工,直至达到合格为止,因返工造成的材料浪费经甲、乙双方共同核定,
折价从承包款中扣除。 2乙方应组织技术过硬、实力强的施工班组,科学合理的有组织安排施工。
五、工期要求:
主体工程天。
工期自 年 月 日算起,麦收、秋收、秋种不放假。
本工期非日历工期,雨天或非乙方原因造成的材料供应不及时,造成停工停产的,工期相应顺延,以施工日记为准。
工期每提前一天奖励500元,拖延一天罚款500元。
六、工程款拨付:
主体工程结束拨付工程款70%,装饰工程结束拨付25%,余款5%在工程竣工验收合格后,一个月内付清。
七、工程款拨付条件:
1、分部分项工程按施工进度计划完成,并经甲方验收达到合同标准要求。
2、文明施工、工完料清、施工场地整洁有序。
八、安全施工要求:
乙方应提高安全意识,加强工人安全教育。施工期间所发生的责任一切安全事故,花费在500元以内者,均由乙方自行承担。花费在500元以上者,如因乙方违规作业所造成的一切经济损失均由乙方全部承担。
九、其它约定事项:
1、班组长每天早上7:30及下午6:30到项目部签字报道,有事提前书面请假。迟到超过5分钟者,每分钟罚1元,超过30分钟者视为无故不到,无故不到工地者,一次罚50元。
2、开工后,乙方班组技术员必须到位,跟班现场作业。
3、领取生活费及工程款,必须先由主管技术员签字。
4、乙方应尊重甲方,服从甲方领导。
5、乙方有义务保持施工现场的清洁卫生,不得损坏现场的设施及邻居的财产,所造成的损失及邻里纠纷由乙方自行解决。
6、乙方应做好自己的模板支设成品保护工作,因未保护好而造成破坏的自行整改。
7. 乙方负责工程中所有预留洞、预埋件及预埋钢筋的模板留口和钻孔工作,负责预制板及排线道安装后的缝隙吊模工作。
十、补充条款:文明施工、工程质量管理细则
(一)十不准:
1、非施工人员不准进入施工现场。
2、施工现场不准乱堆放模板材料、架材。
3、施工人员不戴安全帽,没有安全防护措施不准施工。
4、不准聚众赌博。
5、不准酗酒、行凶、打架、斗殴。
6、不准随意更改配合比。
7、模板、木方不准乱用,能使用的模板头不准下楼。
8、检查出的模板支设问题不返工或整改不彻底,不准进入下道工序。
9、图纸设计意图表达不明,理解不清不准施工。
10、不准在施工现场住宿,不准在施工现场大小便。
(二)为了确保工程质量,更好落实本合同各项条款落实,适当采取经济手段来管理,特别制定以下奖罚标准,希望乙方单位配合。
1、不按设计图纸及甲方要求施工者,发现一次罚款100元。
2、浇筑混凝土时要有专人跟班作业,无人跟班一次罚款100元。
3、支模后,水平、垂直、平整,超过规范要求者,一处罚款50元。
4、通长模板必须挂线校直,违者每发现一处罚款50元。
5、模板加固不牢引起爆模及跑浆的,发现一处罚款100元。
6、模板不刷隔离剂、构造柱不粘海绵胶条施工者,发现一处罚款50元。
7、混凝土强度达不到规范要求,擅自拆模者,发现一处罚款100元。
8、高空作业不系安全带,不戴安全帽,穿拖鞋者,每次每人罚款20元。
9、施工中,打架、斗殴者,不论任何原因双方各罚款200元,领导加倍。
10、各班组长及工人酒后上班者,发现一次罚款200元。
11、不服从甲方管理者罚款500元。
12、除看场外,施工中楼栋内不准住宿,如发现每人每次罚款50元。
13、每天下班前,乙方应自觉清理所用材料,不能乱扔乱放,如发现达不到要求者,罚款100元。
14、模板支好在钢筋绑扎前,应将模板上的杂物及锯沫清理干净,违者一处罚款50元。
15、施工现场所有甲方机械、材料、工具归甲方所有,乙方不得转借、贩卖,否则,发现一例罚款500元。情况严重者加倍罚款。
十一、本合同自双方签字后生效
如有一方违约,将负担一切责任。
十二、如果乙方不自觉屡行本合同,甲方有权单方面解除合同,另找施工班组施工,到时合同自动终止,工程款不予结算。
十三、如工程存在质量问题,乙方不维修或修复后达不到甲方要求,甲方可找施工班组维修,价款从质量保修金中扣除,如工程款不足,甲方有权追偿工程款。
十四、本合同甲方拥有最终解释权。
发 包 人:
承 包 人:
合同签字日期:年 月 日
公司木工承包合同范本
甲方负责人:
乙方负责人:
依照《合同法》及国家相关法律、法规规定,遵循平等、自愿、公平和诚实守信的原则,现甲、乙双方经充分协商,就 万源市新店高山移民安置房 木工、模板及支撑制作、安装及其它相关工作和所有消耗材料、机械设备、工具等承包事宜达成一致,特订立本合同。
第一条工程概况
工程名称: 万源市新店高山移民安置房
工程地点: 万源市新店乡
第二条 工程承包单价及范围
1、按建筑面积/m2进行费用结算(坡屋面按水平投影计算增加工程量)
2、工程承包范围为本工程及与本工程相关的木工、模板、支撑的制、安及其它工作(包括辅助材料)。
包括木工制作、安装、搭拆、吊运、转运、对拉杆、穿墙管、蝴蝶扣、火钩、钉子、铁丝、封口胶、安全带、安全帽、设备、工具、清理、清扫等,并包括夜、雨天加班费用。
第三条、工程工期
1、工期要求:
年
年
如甲方原因造成工程不能正常运行,由甲方负责,如因乙方原因造成工期不能满足要求,由乙方负责并赔偿甲方损失。
2、乙方应编制该工程从开工至竣工验收时的施工进度计划(并报甲方审核后照进度计划严格实施),并执行甲方的进度计划安排(包括新调整的进度计划)。
3、若延期一天工期,罚款元提前一天奖励
第五条 工程质量标准
所承包工程范围内的工程质量必须达到合格工程标准,力争优良。
第六条 甲方责任和义务
1、 负责统一制定各项管理目标,对工程质量、工期、安全生 产、文明施工监督、检查和验收。
2、 协调现场工作关系。
3、 根据工程进度情况要求乙方增减施工人数,满足施工生产 需要。对施工质量低劣、技术差、不服从指挥、有违法乱纪不符合行业规定行为的人员予以教育、处罚和清退。
4、 按双方约定向乙方支付劳务费用及进度款。
5、 协助乙方办理现场施工人员出入证件、购置服装、购置三保设备。
第七条乙方责任与义务
1、 遵守国家政策和法律法规遵守建筑单位(业主方)、监理 单位和甲方的相关规章制度,文明施工,做好上岗前的安全培训、教育工作,防止事故发生,并做好环境和职业健康安全、劳动保护等三级教育工作。
2、 严格按照该工程设计图纸、施工验收规范、有关操作规程要求及施工组织设计,精心组织施工,确保工程质量达到约定的标准,对本工程劳务承包范围的所有工程质量向甲方负责根据业主或甲方的计划要求(包括调整后的计划),合理组织,科学安排作业计划,投入足够的人力、物力,保证工程进度、质量、安全和工期。乙方须承担由于自身责任造成的质量返修、工期拖延罚款及各种损失。同时依法承担相应风险和安全事故的责任。
3、 乙方自身配备的管理人员、技术员、安全员坚守岗位。技 术工人必须按国家规定持证上岗。所有管理人员及特种作业人员的证件的原件交给甲方统一管理 ,以便备查。
4、 服从甲方和业主的监督、检查、管理接受甲方和业主有 关人员对质量、进度、技术、安全生产、文明施工、环境保护等方面
的管理。接受甲方随时检查设备、材料保管、使用情况及操作人员的有效证件、持证上岗情况。
5、 做好施工场地周围建筑物、构筑物和地下管线及已完工程 部分的成品保护工作。因乙方责任发生损坏,应自行承担由此造成的一切经济损失及各种罚款。
6、 按甲方统一规划堆放材料、设备并自行妥善保管。
7、 按国家政策规定与每个务工人员签订《劳动合同》,并按合 同所约定的条款,按时支付务工人员工资(务工人员工资每月造册备案,每月25日交于甲方资料员处),并承担因此项工作不到位而引起的纠纷或当地建设行政部门的处罚及责任后果。
8、 为施工人员配备必要的合格的劳动保护和安全防护用品 (如安全帽、安全带、工作服、手套及其它相关的防护用品),违反规定时按相关制度处罚。
9、 进场施工人员要求具备思想素质好、身体健康、技术熟练 等条件禁止18岁以下的未成年人和55岁以上的老人及体弱病残人员进场施工禁止使用不法人员,乙方应承担因使用以上不合格人员而引起的责任和后果。
10、 甲方在资金暂时不到位时,乙方应尽量对其施工人员做好 解释工作。若未按期拨付工程款,甲、乙双方共同协商解决。
第八条 履约保证金的缴纳及返还
1、 为有效履行该工程劳务承包合同,在签订本劳务承包合同时,乙方自愿向甲方缴纳该工程的劳务履约保证金壹万元整(此履约保证金不计息)。
2、 该履约保证金作为乙方对该工程的劳务承包有效履行的保 障。
3、 履约保证金的返还:
主体竣工验收合格后返还。
第九条环境保护、安全生产和文明施工
1、 甲方应集中组织对乙方进场施工人员进行安全生产、文明 施工、环境保护以及相关制度等方面的教育依据国家法律法规及相关规章制度,监督、监控乙方的相关工作实施情况,使其体系有效运行。
2、 乙方应遵守工程建设安全生产有关管理规定,严格按安全 施工标准进行施工在安全、文明施工和环境保护方面须达到相关规定标准、目标和要求。加强对现场操作人员的安全教育认真落实安全措施,采取必要的安全防护措施,消除事故隐患,确保安全生产随时接受安全检查人员依法实施的监督检查。由于自身安全措施不力及违章操作造成事故,承担一切责任后果和经济费用。发生质量、安全事故,乙方应按有关规定立即报告甲方有关部门,同时按国家有关法律规定对事故进行处理。
甲 方:(十堰)医药有限公司 乙 方:
质量是生命,安全出效益。为确保该工程按时按质竣工验收,现将该工程所有木工作业承包给乙方,特定如下合同:
一、承包方法:
1 承包形式:单包工
2 工作量:地面铺贴20元每平方,房间地脚线4元每米,卫生间墙、地面22元每平方,楼梯踏步32元每平方,踏步脚线9元每米,一楼大厅墙面32元每平方, 楼梯间墙面(400800)25元每平方
二、工程进度:按甲方及业主要求,总工期 天,必须按甲方制定的生产小段进度计划如数完成,乙方如完不成生产任务,甲方有权采取小段罚款进行制约。
三、质量上:项目部对该工程质量管理目标——一次性验收合格,争创优质主体。乙方必须熟悉图纸、按图纸施工精选技术力量过硬、素质高的施工队伍,保证正常的使用功能,使业主、甲方满意,确保竣工验收顺利圆满。
四、安全上:必须保证施工安全,杜绝任何大小事故。乙方必须配备安全员,安全帽由各工种自备,但乙方需购置符合国家安监合格产品,对职工要签定好安全合同,分项工程要有安全技术交底,服从现场安全管理,发现隐患及时汇报,所有施工中的安全由乙方(承包人)负责,甲方不承担任何责任。
五、文明卫生 1 现场每天保持整洁,讲文明、讲卫生,工种间互相协调、配合、不争不吵,给业主和监理留下好印象。材料进场堆放整齐、垃圾归堆,材料每天做到工完场清、不浪费,发现浪费加倍罚款。 2施工垃圾应运至指定堆放地点;剩余饭菜禁止乱倒,应倒入指定的桶内;不随地大小便、不说脏话、不交头接耳、不酗酒、不成帮结派、打架斗殴、不赌博、不看色情录像和书籍;服 从门卫管理,遵守进出时间;语言文明,不酒后闹事,班组和职工之间一定要签定好职工治安责任制合同。
六、罚款制度 施工不带安全帽罚款50元人次;帽带不扣罚款20元人次;赤膊穿拖鞋施工罚款50元人次;悬空抛物罚款100元人次;井字架吊篮乘人罚款100元人次;宿舍内私拉电线罚款50元次;烧电热水器、电炒锅、电炉罚款50元,并没收;点白日灯罚款20元,酗酒闹事、打架斗殴出现一次处以200-500元的罚款,除追究其责任外,情节严重的交当地执法部门处理;乱倒剩余饭菜罚款20元;在新建楼内大便罚款100元;不服从现场管理、指出问题而不及时整改者罚款100元。
七、合同期内乙方必须信守合同。如乙方在施工中质量和进度等达不到业主和甲方的要求,甲方有权中途更换承包人和采取其他制约措施;如乙方无理终止合同、合同期内自己退场或未解除合同前退场,承包金额将永久拒绝支付。
八、保修:验收合格,双方签字之日起,保修________年。
九、付款方式 按工程进度付款。 工程完工,验收合格,一个月内付清95%工程款,余款在保修期________年后付清尾款5%。
十、此合同一式三份,双方签字后生效,各执一份为凭,存档一份,并作为甲乙双方当事人法律依据。
甲方: 乙方:____日期:________年____月____日
木工,是一门工艺,一门独有的技术,也是建筑常用的技术,家装木工 承包合同 怎么写呢以下是小编整理的家装木工承包合同,欢迎参考阅读。 家装木工承包合同范x一 甲方:(发包方) 乙方:(承包方) 本着互相信任的原则,就甲方的木工工程达成以下协议。
第一条 工程概况
1、装修施工地点:
2、工期:
3、本项工程预计费用元人民币。
第二条 材料供应的约定
1、甲方提供的材料 乙方必须至少提前三天向甲方提出下一工序需要购买的材料清单,并注明所需要材料的数量。甲方应按时提供乙方需要的材料。 甲方负责采购供应的材料应符合设计要求的合格产品,并应按时供应到现场,甲乙方应办理交接手续。乙方如发现甲方提供的材料有质量问题或规格差异,应及时向甲方提出,甲方仍表示使用的,由此造成工程损失,责任由甲方承担。 乙方自带施工的必须工具(锥子、切割片等),要保证安全性、良好使用性,乙方自行承担工具维修费和损耗费用。
第三条 有关安全生产和防火等的现场管理约定:
1、严格遵守规定的装饰装修的施工时间,降低施工噪音,减少 环境污染 ,处理好由施工带来的扰民问题及与周围单位、住户的关系。
2、未经甲方同意及有关部门批准,施工中不得随意拆改原建筑物结构及各种设备管线。
3、工程竣工未移交甲方之前,负责对现场的一切设施和工程成品进行保护。
4、乙方施工人员的一切安全问题由乙方自行负责。
5、乙方施工人员必须服从甲方管理员的管理。
第四条 关于工程价款、承包内容、施工工艺、结算的预定:
1、石膏板吊顶 元㎡
2、灯带 元㎡
3、中空密度板造型线条 元
4、背景墙大芯板打底 元㎡
5、面板柜子 元㎡
6、窗帘盒 元
7、做假梁 元(40分以上)
8、包门套 单面 元 双面 元
第五条 付款方式
1、对于双包的工种,材料进场甲方预支材料款给乙方
2、按工程进度给于乙方预支工人生活费
3、各工程完工以前付到造价的70%
4、工程竣工(业主验收)付到造价的100%
5、甲方未按工程进度支付的,乙方有权停工
第六条 纠纷处理方式: 因工程质量双方发生争议时,双方协商解决当事人不愿通过协商、调解解决,或协商、调解不成时,可以按照本合同约定向人民法院提起拆讼。
第七条 符则
1、本合同经甲、乙双方签字(盖单)后生效。
2、本合同签订后工程不得转包。
3、本合同一式两份,甲、乙双方各执一份。
4、合同有效期至 甲方签字(盖单): 乙方签字(盖单):____日期:____日期: 家装木工承包合同范x二 建设单位(甲方): 承包单位(乙方): 甲方有 ,现委托乙方对该卖场 木工工程 部份进行广告装修。该工程所用的材料由甲方负责,乙方按甲方图纸进行施工(附图纸)。
一、工程名称:室内装修 木工 工程
二、施工地点:
三、木工工程总造价:按甲乙双方签订的价格(附价格表、施工验收检准)
四、付款方式:工程完全完工并经业主和甲方项目负责人验收合格后,甲方贰拾天内支付乙方95%的 工程款 ,余下的5%的工程款为质量 保证金 ,甲方需于三个月后支付给乙方。
五、施工期限:从________年____月____日起至________年____月____日止 共 天内完成,如因甲方改变设计方案,或甲方材料不能按时到位,工期将顺延。
六、保修:保修期为 半________年,保修期内属乙方施工质量问题,乙方需进行保修,保修所产生的费用(包括材料)均由乙方负责,或由甲方从质量保证金中扣回若费用超过质量保证金,甲方有权在乙方的其他工程款中扣回。(如属人为损坏或天然灾害问题,不在保修范围之内)。
七、责任:
(1)、乙方在进场施工前需检查墙体结构的完整、对上工序完工的基本验收,并作好验收交接。对接收甲方的材料时应作数量和质量的验收,验收后出现的短缺和损坏由乙方负责。另如发现乙方人员偷取甲方的材料,一经证实将以一罚十处理。
(2)、乙方未经甲方同意不能变更施工方案,否则造成的经济损失由乙方负责。
(3)、施工过程中乙方应注意消防、 工伤 的安全,严格按照甲方的施工指引进行施工,施工期间由于乙方的原因所造成的意外损失和工伤,由乙方自行负责。
(4)、因乙方的原因未能按工期完成的,按延误天数每天扣罚总工程款的5%.
八、本合同一式两份,甲、乙双方各一份。由双方签字后生效,全部工程结算后自行终止。
九、单价 室外铝塑板招牌 室内基层打底 室内铝塑板 室外铝塑板包柱 甲方: 乙方: 签约代表: 签约代表: 签约日期:________年____月____日 签约日期:________年____月____日 家装木工承包合同范x三 业主(以下简称甲方): 身份证 号码: 联系电话:施工方(以下简称乙方): 身份证号码: 联系电话:甲乙双方本着友好合作的态度,按照《 民法典 》等相关法律,在平等公正的情况下签订合同如下:
一、工程概况 工程地址:
二、价格 木工清包工费:。
三、付款方式
1、施工人进场,预支生活费:
2、其余款根据施工进度分期支付 ,工程完成付 经验收合格,____日内结清其余款项 元。
四、设计
1、甲方须向乙方提供图纸一套,付装修内容明细表,并负责交底工作。
2、甲方若无图纸,须向乙方交代清楚要求,乙方施工前须画草图让甲方认可。
3、如有项目变更,经双方协商,工程相应调整。
五、材料
1、乙方应提前3天向甲方提供需购材料清单,甲方应在3天内及时采购材料供施工方使用,双方应各自承担各自拖延工期的责任和经济损失。
2、未经甲方同意,乙方不得自行采购材料,若已采购,甲方有权无条件拒绝使用并可拒绝支付材料的费用。
3、乙方应帮甲方收货,核对数量和配件的准确性。
4、乙方应保证施工期间在本小区内没有双包和半包的工程。
5、乙方应做好对施工完成的成品和甲方所提供的材料、设备的保管工作,禁止闲杂人等进入现场。由于乙方保管或安装不当造成损失的,应由乙方负责赔偿。
6、未经甲方许可,乙方不得携带任何建材出门,若发现此类现象,按材料价格的3倍从人工费中扣除。
六、工期 从________年____月____日起至________年____月____日止,工期为 天,因甲方因素拖延,工期顺延,因乙方因素拖延工期,甲方可相应扣除乙方的装修费。
七、材料搬运 甲方材料送至工程所在地,乙方施工人员应无条件协助搬运。
八、垃圾清运
1、垃圾袋装化,垃圾应日日清。
2、垃圾应由乙方清运至物业指定的垃圾堆放场所。
九、劳动力管理
1、开工前乙方应向甲方提供所有施工人员的身份证复印件。
2、未经甲方许可,所有人员不得在施工现场过夜。
3、甲方应及时替乙方办理小区出入证件并支付相关费用。
4、在合同价内,乙方应提供数人次跟随甲方挑选材料。
5、乙方未经甲方同意不得任意条换施工人员,每天工地必须保持人以上的施工人员。
6、未经甲方同意,任何情况下乙方不得停工或殆工。不得将工程转包他人。
十、施工机具 乙方自带施工所需工具,并保证工具的安全性和良好使用性,乙方自行承担工具的维修费。 十
一、工地现场管理
1、 现场禁止使用明火,现场禁止吸烟。
2、 油漆材料必须和其他材料分开放置。 十
二、维修
1、 因乙方施工原因导致的质量问题,乙方应在甲方通知乙方后3天内及时维修。
2、 若乙方未能按合同及时完成维修,甲方可以安排其他施工队进行维修工作,所产生的费用按实从装修费中扣除。 十
三、合同附件
1、 施工项目清单及明细表。 十
四、合同争议 出现争议甲乙双方友好协商解决,协商不成可向争议所在地法院提起 诉讼 。 十
五、装修要求 a,包门套、窗套、腰线、角线、柱边、吊棚、石膏线等
1、门、窗套线宽不大于3,厚度不大于3。
2、要求横x竖直,2米内1每工件外露部分倒角145,所有阴阳脚都要靠角尺。
3、垂直贴在门套上检查垂直度。
4、注意所有门要等高等宽。 b,储物柜:木工板低架、实木线收口,内部有隔断,(多组,见详细图纸)。壁柜验收要求:
1、 要求横x竖直,2米内1,每工件外漏部分倒角145,所有阴阳脚都要考角尺。 c,厨房橱柜:
1、 提前咨询柜体内水管布置。 d,其他说明要求:
1、 保证原先商定好的装潢设计思想,不能擅自改动。如有变化,必须征得业主同意。
2、 业主购买的柜门、房门、包括所购的材料、设备等协助搬运至现场及安装。
3、 除上述装潢要求外,如有增加或改动工作,不超过工程的10%,不增加 工资 。
4、 工程为清包,业主者提供材料。施工工具等设备由施工承包人自备自理。
5、 施工方必须保证施工质量,发生施工质量问题,施工方应及时予以改正。竣工验收时发 现质量问题,施工方应立即予以改正,在未达到业主的整改要求前业主有权拒付人工费
6、 施工人员要文明施工,爱护室内原有设施,禁止野蛮施工。业主所有物品未经许可,不 得擅自处理。业主对表现不好的施工人员有权要求掉换,承包人不得拖延。
7、 施工方负责及时清理建筑垃圾,工程施工结束后,施工人员负责场内建筑垃圾清运。
8、 承包人应加强对现场施工人员防火防盗安全教育,如违反操作规程发生安全事故,承包人自行负责,如对业主造成损失要进行赔偿。施工人员不得在施工现场违法乱纪,一旦发生问题,后果自负。 甲方:(签章) 乙方:(签章) 签约日期: 签约日期:
2023园林建设木工工程承包甲方: ________________________________(简称:甲方)
乙方:________________________________ (简称:乙方)
经甲乙双方共同协商,甲方将 项目工程以包工,包制模,铁钉,铁线,电缆,电锯电片及机械所有的电缆电线工具,包图纸上木工制安及所有木工工程一次性承包给乙方施工,为安全保质保量金,工程结束后给予返还。
一、承包单价
乙方所承包的木工工程,其单价按建筑面积的( )元/m2(包括基础地下室设施及屋顶斜屋面n型线条主体),按此单价为最终结算价,甲方不另追加乙方任何费用,面积计算以图纸为准。
二、承包范围
乙方按设计图纸,设计变更完成该工程所有的木工工程,(含附属零星工程木工及基础设施的制安,负责工程完工后,所有的模板,方条,顶木,步步紧,方条等的清理及按甲方要求制定的地方分类堆放好)。
三、乙方负责
1、乙方应付责组织本工程所需要的熟练工人,机械工具辅助材料,熟悉施工图纸规格按照设计图纸施工规范及安全生产条列,进度计划国家品质标准施工。
2、服从项目管理人员及施工员统一指挥,调配和检查,遵守项目人员制定的各项规章制度,不准随意浪费甲方原材料,如发现乙方随意浪费,甲方有权要求乙方按原价加倍赔偿。
3、乙方不得在工地上无理取闹不服从甲方现场管理人员统一指挥调度及阻止别的施工班组施工的,发现一次罚款500元,累次不改甲方有权单方面终止合同,乙方按实际完成工程量的60%结算,并自动退场。
4、主体施工过程中,乙方应按时,按质,按量完成施工任务。不准有爆木。漏浆现象,发现有出以每处50—200元罚款,并即时处理,因木工验收不合格造成返工,甲方有权要求乙方加倍赔偿一切浪费的原材料及需别的施工班组配合返工所需人工工资,工程所有爆木,漏浆处,乙方应及时处理掉。尾期工程中需要制安的应随叫随到,不到的话,甲方有权请他人做,其工资按市场价格双倍从乙方未付工程款中扣除,影响工期的按合同规定处罚,乙方应无异议。
四、甲方负责
1、负责对乙方的图纸技术交底及安全三级教育,指导,检查乙方施工过程中的施工质量。
2、按合同约定按时支付工程款。
3、无偿提供乙方的住宿及生活用水用电,(不含电磁炉用电)
五、工期要求
1、乙方应严格按照项目部制定的各项施工进度计划进行施工,具体进度计划按项目部制定的施工进度计划。
2、乙方不能按甲方进度计划完成工期内的工程量时,甲方有权高价在外面请人帮忙完成,乙方无权阻扰,其工资从乙方工程进度款中扣取,工期拖延一天处以500—5000元的工期处罚金,按工期计划乙方提前完成应给与奖励。
3、因乙方原因造成工程停工三天以上,甲方有权单方面终止合同另找施工队,结算按实际完成工程量的60%结算,结算时间按工程主体全部封顶后结算,余下的部分作为重组新班组和甲方的损失费用。
六、质量标准
规格按照施工图纸设计变更通知及现行的国家有关强制性规范规定施工,并达到国家工程品质验收合格标准,如有返工给甲方造成材料浪费或延误工期的,甲方有权追究其赔偿责任并罚款,费用从乙方工资中扣回。
七、安全要求
1、乙方工人进入施工现场都必须遵守安全操作规程,佩戴安全帽,穿工作服,穿胶鞋上班。
2、上班时间不许喝酒,打闹,严格安全生产条例方针,及项目部组织所要求的安全知识讲座内容交底,进行施工。
3、如乙方在施工过程所造成的任何安全事故,由乙方负全部责任和费用及事后处理,与甲方无关。
4、不带安全帽,穿拖鞋,喝酒上班的发现一次每人每次30元罚款,此款从工资中扣除,并通报批评,现场严禁带小孩或社会闲杂人员进入工地,住宿,逗留。
八、付款方式
本工程第一次按工程总量的三楼付款80%,然后按月进度工程量的80%付款。余款在完成承包内工作后两个月内结清
九、其他
1、本合同未尽事宜,双方可根据情况随时协商补充,补充协议与本合同具有同等效力。
2、本合同书自签字之日起生效,工程竣工,工程款全部结清后本合同法律效力自行终止。
3、本协议一式两份,双方各持一份,同时具有相应法律效力。
甲方(签章)________________ 乙方(签章)________________
____ 年 _____ 月 _____ 日____ 年 _____ 月 _____ 日
15位用户关注
48位用户关注
74位用户关注
26位用户关注
38位用户关注
66位用户关注
78位用户关注
24位用户关注
21位用户关注
50位用户关注
50位用户关注